FY2027-04 LTP Citric Acid Skid Installation with Premier Mechanicala.
°° Page 1 of 2
Kodiak Island Borough
Agreement
Page 1 of 2
Project: LTP Citric Acid Skid Installation with Premier Mechanical
Contract No. FY2027-04
This CONTRACT ("Contract"), between the Kodiak Island Borough, Alaska, herein called the Borough,
acting by and through its Borough Manager, and
Premier Mechanical, LLC
Company Name
1623 Mill BE Road #5, Kodiak, AK 99615
Company Address (Street or PO Box, State, Zip)
a/an ❑ Individual ❑Partnership ❑Joint Venture ❑Sole Proprietorship ❑Corporation
incorporated under the laws of the State of Alaska, its successors and assigns, herein called the Contractor,
is effective the date of the signature of the Borough Manager on this document.
The Contractor, for and in consideration of the payment or payments herein specified and
agreed to by the Borough, hereby covenants and agrees to furnish and deliver all the materials
and to do and perform all the work and labor required in the construction of the above -
referenced project as bid by the Contractor, which bid and prices named, together with the
Contract Documents (as hereinafter defined) are made a part of this Contract and accepted as
such.
2. It is distinctly understood and agreed that no claim for additional work or materials, done or
furnished by the Contractor and not specifically herein provided for, will be allowed by the
Borough, nor shall the Contractor do any work or furnish any material not covered by this
Contract, unless such work or materials is ordered in writing by the Borough. In no event shall
the Borough be liable for any materials furnished or used, or for any work or labor done, unless
the materials, work, or labor are required by the Contract or on written order furnished by the
Borough. Any such work or materials which may be done or furnished by the Contractor
without written order first being given shall be at the Contractor's own risk, cost, and expense
and the Contractor hereby covenants and agrees to make no claim for compensation for work
or materials done or furnished without such written order.
3. Payment under this Contract shall not exceed Three Thousand Four Hundred Eighty dollars
and Fifty Cents ($3,480.50) . The Parties acknowledge that funds for the payment of this
contract are subject to the availability of funds lawfully appropriated for that purpose.
4. The Contractor shall furnish and deliver all materials and perform all work and labor, in all
respects to the satisfaction of the Borough, within thirty (30) calendar days after the Notice
to Proceed is issued. The Borough will issue the Notice to Proceed upon the arrival of the
new skid on -site at the LTP.
5. It is expressly understood and agreed that in case of the failure on the part of the Contractor,
for any reason, except with the written consent of the Borough, to complete the furnishing and
delivery of materials and the doing and performance of the work before the aforesaid date, the
Borough shall have the right to deduct from any money due or which may become due the
CONTRACTOR
Premier Mechanical, LLC
Company Name
P1,
Signature of Authorized Representative
Sean Rauwolf
Printed Name of Authorized Representative
der06/15/2026
Page 2 of 2
Contractor, or if no money shall be due, the Borough shall have the right to recover Liquidated
Damages as described in the Special Conditions for each calendar day elapsing between the
time stipulated for achieving substantial completion of an individual phase and the actual date
of completion of that phase in accordance with the terms hereof; such deduction to be made,
or sum to be recovered, not as a penalty but as liquidated damages. Provided, however, that
upon receipt of written notice from the Contractor of the existence of causes over which the
Contractor has no control and which must delay furnishing of materials or the completion of
the work, the Contracting Officer may, at his or her discretion, extend the period specified for
the furnishing of materials or the completion of the work, and in such case the Contractor shall
become liable for liquidated damages for delays commencing from the date on which the
extended period expires.
6. The Contractor further covenants and agrees that the entire construction will be done under the
administration of and to the complete satisfaction of the Borough subject to the inspection at
all times and approval by any regulatory agency, and in accordance with the laws of the State
of Alaska and the Borough.
7. For purposes of this Contract, Contracting Officer means Borough Manager, or any other
person designated by the Borough Manager.
8. The Contractor is an independent contractor and not an employee or agent of the Borough.
9. Contract Documents shall have the meaning ascribed by the General Conditions of the
Construction Contract which can be found at Projects Office I Kodiak Island, AK - Official
Website, and include but are not limited to this Contract, the General Conditions of the
Construction Contract, the Special Conditions, and the following listed documents:
(1) Exhibit A: Premier Mechanical Proposal Dated June 10, 2026
(2)
IN WITNESS WHEREOF the parties hereto have executed this Contract and agree to its terms and
conditions.
O AK ISLANDJBOROUGH
I A Ajkl A 1
Vh--
g ature of Borough Manager
Aimee Williams
Printed Name
IS '�/Vu
Date
(;'�M �
Borough Clerk (Attest)
y 2
D
D_
D m
to
O
N
-n
p
0- n=
— n
^'
p
G.
0
M
v
.tee
(D
3
3
w
'a*
ofo
o
c
(D v
(D
r*
O
I-
p
co'
S_=
u,
o,
O
o
o
a
a �
o
o
v
of
m
m
3�
n v'
-h
�m
v
T
O
y
a
C
m
r+
of
7
a
7�C
a
L
3
m
=
=
=
(fin
(D
3
ry
3
O
r)
v
D�
7
�
a
a
m
_a
Qq
N
m
A
(D
Q
I--
Owl A
00
00
00
00
F+
(D
r
y
D
�-
p
D
p
G1
to
n
0
m
m,3-r
(D
O
(D
O
*<
(D
n
O
.�
A
a
m
w
=
m
w
W
m
d
rCUO
r
a'fu(Tw
Q.
p
p
m
CL
W
7C
o30
Q
a
'p
Oq
ca
y
S
A
m
fD
7
A
c
Ln
NJ
to
in
v►
to
to
to
to
to
to
W
Ln
W
w
w
w
N
N
W
V
fD
I-+
N
to
N
U7
N
O
UA
U1
00
In
to
In
to
Ln
O
O
O
Ln
O
O
O
00
O
O
O
to
ti►
to
to
to
to
ti►
to
to
to
to
a1
F+
N
ODD
000
l0
V?
A
A
A
!J1
V
O
O
N
O
A
O
A
O
O
to
t!t
Ui
In
In
O
O
C
O
C
C
O
C
O
O
0
O
O
O
O
O
O
O
O
�
x
a
►�
00
_00