Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
FY2020-34 Outdoor Warning Siren System Replacement
FYaoAo --3 May 13, 2020 KODIAK ISLAND BOROUGH 710 MILL BAY ROAD KODIAK, ALASKA 99615 Kodiak Island Borough ENGINEERING & FACILITIES DEPT. 710 Mill Bay Road Kodiak, Alaska 99615 Phone (907) 486-9394 Fax (907) 486-9394 NOTICE OF INTENT TO AWARD TO: Mr. Brent Gambrel, VP/GM Systems Federal Signal Corporation 2645 Federal Signal Drive University Park, Illinois 60484 Subject: Notice of Intent to Award Project: Outdoor Warning Siren Replacement Mr. Gambrel: The Kodiak Island Borough Assembly has reviewed and awarded the contract for Outdoor Warning Siren Replacement for the Kodiak Island Borough, Contract No. FY2020-34 to Federal Signal Corporation in the amount of $530,741.54 at the May 7, 2020 regular meeting. Please submit your performance and payment bonds, and certificate of insurance to the Kodiak Island Borough Engineering Department within ten (10) business days after receiving this notice. Also please include a list of subcontractors, their mailing address and phone numbers. These items may be sent or delivered to: Kodiak Island Borough 710 Mill Bay Road Kodiak, Alaska 99615 Attn: Engineering/Facilities Department Email: dconrad(@kodiakak.us and mgandel(cDkodiakak.us If you fail to execute the said Agreement and furnish said bonds and certificates of insurance within 30 days from this Notice, said Owner will be entitled to consider all your rights arising out of the Owner's acceptance of your bid to be abandoned and as a forfeiture of your Bid Bond. The Owner will be entitled to such other rights as may be granted by law. You are required to return an acknowledged copy of this Notice of Intent to Award to the Owner. Dated th' th day of y, 2020. By: _ ..% Michael Pow rs, Borough Manager �NDeD� ON G ATTEST: (9 Ta fa Welinsky, Borough Clerk 3 SKA 'Cl ACCEPTANCE OF INTENT TO AWARD Receipt of the Notice of Intent to Award is hereby acknowledged. Dated this 147�th— daMay 2020. By: -6 ti✓ 11 Brent Gambrel, VP/GM Systems If you have any questions, please contact the Engineering and Facilities Department at (907) 486-9340. If you fail to execute the said Agreement and furnish said bonds and certificates of insurance within 30 days from this Notice, said Owner will be entitled to consider all your rights arising out of the Owner's acceptance of your bid to be abandoned and as a forfeiture of your Bid Bond. The Owner will be entitled to such other rights as may be granted by law. You are required to return an acknowledged copy of this Notice of Intent to Award to the Owner. Dated trmlo f y, 2020yin. Michael Pow rs, Borough Manager ,✓" cj�- B \ �s a O r Y ATTEST: I Ta fa Welinsky, Borough Clerk c ACCEPTANCE OF INTENT TO AWARD -- Receipt of the Notice of Intent to Award is hereby acknowledged. Dated this day of May 2020. By: Title: If you have any questions, please contact the Engineering and Facilities Department at (907) 486-9340. I '1 `� (J CERTIFICATE OF LIABILITY INSURANCE DATE(MWDl1lYYY11 D�I�Ep THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. TH15 CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the pollcy(les) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WANED, subject to the terms and conditions of the policy, certain policies may require an endorsement, A statement on this certificate does not confer rights to the certificate holder In lieu of such endomement(s). PRODaCIA Aon Risk Services Central, Inc. Chicago IL Office CONTACT NAME: PArc HONN.. 111 (866) 283-7122 SNP: (800) 363-0105 EMAIL 200 East Randolph Chicago IL 60601 USA ADDRESS: GL6939082 M10111721102111 2021 11 Dl D INStRrEINSI AFFORDING COVERAGE NAM INSURED INSURER: National union Fire Ins cc of Pittsburgh 19445 Federal Signal Corporation 2645 Federal Signal Drive University Park IL 60466 USA INSURER B: The Insurance Co of the State of PA 19429 INSURERC: New Hampshire Insurance Company 23841 CLAIMSMADE X OCCUR ❑ INSURERS: American Home Assurance Co. 19380 INSURER E: 11/01/2019 11/01/2020 MSURERF eF veoerva rCRTICIraTC MI IUCCC• A7nnR1THA7R RCVIR1mM NI IMRCR- THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. Limits shown am as requested MBRTYPE OF mBUMNCE ASLMon 6UBR PO YNUMBER POLICY Err POLICY ESP LIMIR A X COMMERCIALOENEM.I.All GL6939082 M10111721102111 2021 11 Dl D EACH OCCURRENCE $1,000,000 GL Premise DAMAGETORENTED 51,000,000 A CLAIMSMADE X OCCUR ❑ GL6939081 11/01/2019 11/01/2020 PREMISES GL Products MEDEXPIA,r..;anml $10,000 PERBONALSADVINJURY S1,0DO,000 GENT AGGREGATE LIMIT APPLIES PER'. GENERALAGGREGATE 52,000,000 X POLICY [:]FRI F-1LOCPRODUCTS -COMP.OP AGO 56,000,000 Pm .rrc OP-EBO , 53,000,000 OTIffR'. A AUTOMOBILE WBIUTY CA 7093331 11/01/201911/01/2020 COMBINED SINGLELIMIT 51,000,00 AOS A x ANI CA 7093333 11/01/2019 11/01/202D BODILY INJURY (Par mumv) BODILY INJURY IPI, aOlCenn OWNED SCHEDULED VA ALTOS ONLY ALTOS PROPERTY DANAGE HIREOAUTOB Pnr ICWN ONLY AUTOBOI$Y UMBRELLAWB OCCUR EACHOCCURRENCE AGGREGATE EXCESS WB CLAIMSIIADE DrL 1 RETENTION C wO11NERS COMPENSATIONAND WC013778842 11/01/2019 11/01/2020 X PERSTATUTE I 0TH EMPLOYERS' LIFBILTTY ADS E.L EACMACCIDEm $1,000,00 D ANY PROPRIETOR I PARTNER I EXECUTIVE N WC013778843 11/01/2019 11/01/2020 C£FICERIMEMBBe EXCLUDEDT HAVr Muy InNHl MIA CA EL DISEPSEFAEMPLOYEE 51,000,000 11'. d DESS tlewON OFF DESCRIPTION OF OPERATIONS OeIav ELDISEASEPOUCYLIMIT 51,()00,000 DEWRHTON OF OPEMTNIXB I LOCATIONS I VEHICLES PCMID 101. ANSI Rmu,LA BCN d.W. mry M MlaPMa 11 mors 8 p 1. MulMl Kodiak island Borough, its agentsand employees are included as Additional Insured in accordance with the policy provisions of the General Liability and Automobile Liability policies. A waiver of Subrogation is granted in favor of Kodiak Island Borough, its agents and employees in accordance with the of the General Liability, Automobile Liability and workers policy provisions Compensation policies. CERTIFICATE HOLDER CANCELLATION Sz SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE FOA CYPROWBIONS, Kodiak Island Borough AUTHORGEO REPRESENTATIVE 710 Mill say Road Kodiak AK 99615 USA ©19882015 ACORD CORPORATION. All rights reserved. ACORD 25 (2016107) The ACORD name and logo are registered marks of ACORD AGENCY CUSTOMER ID: 10224264 LOC #: A ADDITIONAL REMARKS SCHEDULE Page _ of _ AGENCYNAMED Aon Risk services central, Inc. INEnREG Federal signal Corporation POLICY NUMBER see Certificate Number: 570081771423 CARRIER see Certificate Number: 570081771423 I NAC CODE EFFECTIVE DATE. ADDITIONAL REMARKS THIS ADDITIONAL REMARKS FORM IS A SCHEDULE TO ACORD FORM, FORM NUMBER: ACORD 25 FORM TITLE: Certificate of Liability Insurance INSURER(S) AFFORDING COVERAGE NAIC # INSURER INSURER INSURER INSURER ADDITIONAL POLICIES If a policy below does not include limit information, refer to the corresponding policy on the ACORD certificate form for policy limits, INSR LTR TYPE OF INSURANCE ADOL INSD SEBR VYD POLICY NUMBER POLICY EFFECTIVE DATE IMM/DD/YYl'YI POLICY E%PIRATION DA E (\I M/DD/YYVY) LIMITS WORKERS COMPENSATION c N/A WC013778840 FL 11/01/2019 11/01/2020 B N/A WC013778839 MA, NO, WA 11/01/2019 11/01/2020 C N/A WC013778841 AZ,IL,KY,NC,NH,N3,PA,VA 11/01/2019 11/01/2020 A N/A xBIC4595557 XS WC OH—EL $500,000 SIR applies per policy to 11/01/2019 ms & Condit 11/01/2020 ons ACORD 101 (2001001) D 2008 ACORD CORPORATION. All rights rommed. The ACCORD name and logo m registered name of ACORD ',AIA Document A312T"" .2010 Performance Bond CONTRACTOR: (Name, legal status and address) FEDERAL SIGNAL CORPORATION 2645 Federal Signal Drive University Park, IL 60484 XIMI [li (Name, legal status and address) KODIAK ISLAND BOROUGH 710 Mill Bay Road Kodiak, AK 99615 CONSTRUCTION CONTRACT Date: 5/13/20 Bond No. 285063384 SURETY: (Nance, legal status and principal place ofhusiness) LIBERTY MUTUAL INSURANCE COMPANY 175 Berkeley Street Boston, MA 02116 Amount: Fii 518 nd 54Eighteen Thousand Two Hundred Forty One and 54/100 Dollars Description: (Name and location) Outdoor Warning Siren System Replacement for Kodiak Island Borough, Contract No. FY2020-34. BOND Date: 5/18/20 (Not earlier than Construction Contract Date) Five Hundred Eighteen Thousand Two Hundred Forty One and 54/100 Dollars Amount: ($ 518,241.54) Modifications to this Bond: W None 0 See Section 16 CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) FEDERAL SIGN CORPORATION LIBERTY MUTUAL INSURANCE COMPANY Signature: / Signature: O ^ l V� Name Ph GzAr Name Susan A. Welsh, Aftomey4n-Fact and Title: V P/GM RrA1 and Title: (Any additional signatures appear on the last page of this Performance Bond.) (FOR INFORAMTION ONLY— Name, address and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: AON RISK SERVICES CENTRAL, INC. (Architect, Engineer or other party:) 200 E. Randolph 12th Floor Chicago, IL 60661 This document has Important legal consequences. Consultation with an attomey is encouraged with respect to Its completion or modification. Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. AIA Document A312-2010 combines two separate bonds, a Performance Bond and a Payment Bond, into one form. This is not a single combined Performance and Payment Bond. § 1 The Contractor and Surety, jointly and severally, bind themselves, their hens, executors, administrators, successors and assigns to the Owner for the performance of the Construction Contract, which is incorporated herein by reference. § 2 If the Contractor performs the Construction Contract, the Surety and the Contractor shall have no obligation under this Bond, except when applicable to participate in a conference as provided in Section 3. § 3 If there is no Owner Default under the Construction Contract, the Surety's obligation under this Bond shall arise after .1 the Owner first provides notice to the Contractor and the Surety that the Owner is considering declaring a Contractor Default. Such notice shall indicate whether the Owner is requesting a conference among the Owner, Contractor and Surety to discuss the Contractor's performance. If the Owner does not request a conference, the Surety may, within five (5) business days after receipt of the Owner's notice, request such a conference. If the Surety timely requests a conference, the Owner shall attend. Unless the Owner agrees otherwise, any conference requested under this Section 3.1 shall be held within ten (10) business days of the Surety's receipt of the Owner's notice. If the Owner, the Contractor and the Surety agree, the Contractor shall be allowed a reasonable time to perform the Construction Contract, but such an agreement shall not waive the Owner's right, if any, subsequently to declare a Contractor Default; .2 the Owner declares a Contractor Default, terminates the Construction Contract and notifies the Surety; and .3 the Owner has agreed to pay the Balance of the Contract Price in accordance with the terns of the Construction Contract to the Surety or to a contractor selected to perform the Construction Contract. § 4 Failure on the part of the Owner to comply with the notice requirement in Section 3.1 shall not constitute a failure to comply with a condition precedent to the Surety's obligations, or release the Surety from its obligations, except to the extent the Surety demonstrates actual prejudice. § 5 When the Owner has satisfied the conditions of Section 3, the Surety shall promptly and at the Surety's expense take one of the following actions: § 5.1 Arrange for the Contractor, with the consent of the Owner, to perform and complete the Construction Contract; § 5.2 Undertake to perform and complete the Construction Contract itself, through its agents or independent contractors; § 5.3 Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for performance and completion of the Construction Contract, arrange for a contract to be prepared for execution by the Owner and a contractor selected with the Owner's concurrence, to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract, and pay to the Owner the amount of damages as described in Section 7 in excess of the Balance of the Contract Price incurred by the Owner as a result of the Contractor Default; or § 5.4 Waive its right to perform and complete, arrange for completion, or obtain a new contractor and with reasonable promptness under die circumstances: .1 After investigation, determine the amount for which it may be liable to the Owner and, as soon as practicable after the amount is determined, make payment to the Owner, or .2 Deny liability in whole or in part and notify the Owner, citing the reasons for denial. § 6 If tire Surely does not proceed as provided in Section 5 with reasonable promptness, lire Surety shall be deemed to be in default on this Bond seven days after receipt of an additional written notice from the Owner to the Surety demanding that the Surety perform its obligations under this Bond, and the Owner shall be entitled to enforce any remedy available to the Owner. If the Surety proceeds as provided in Section 5.4, and the Owner refuses the payment or the Surety has denied liability, in whole or in part, without further notice the Owner shall be entitled to enforce any remedy available to the Owner. AIA Document A312- —2010. The American I nstitute of Architects. § 7 If the Surety elects to act under Section 5.1, 5.2 or 5.3, then the responsibilities of the Surety to the Owner shall not be greater than those of the Contractor under the Construction Contract, and the responsibilities of the Owner to the Surety shall not be greater than those of the Owner under the Construction Comma. Subject to the commitment by the Owner to pay the Balance of the Contract Price, the Surety is obligated, without duplication, for .1 the responsibilities of the Contractor for correction of defective work and completion of the Construction Contract; .2 additional legal, design professional and delay costs resulting from the Contractor's Default, and resulting from the actions or failure to act of the Surety under Section 5; and .3 liquidated damages, or if no liquidated damages are specified in the Construction Contract, actual damages caused by delayed performance or non-performance of the Contractor. § 8 If the Surety elects to act under Section 5.1, 5.3 or 5.4, the Surety's liability is limited to the amount of this Bond. § 9 The Surety shall not be liable to the Owner or others for obligations of the Contractor that are unrelated to the Construction Contract, and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations. No right of action shall accrue on this Bond to any person or entity other than the Owner or its heirs, executors, administrators, successors and assigns. § 10 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 11 Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent jurisdiction in the location in which the work or part of the work is located and shall be instituted within two years after a declaration of Contractor Default or within two years after the Contractor ceased working or within two years after the Surety refuses or fails to perform its obligations under this Bond, whichever occurs fust. If the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of titre suit shall be applicable. § 12 Notice to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. § 13 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in Ibis Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 14 Definitions § 14.1 Balance of the Contract Price. The total amount payable by the Owner to the Contractor under the Construction Contract after all proper adjustments have been made, including allowance to the Contractor of any amounts received or to be received by the Owner in settlement of insurance or other claims for damages to which the Contractor is entitled, reduced by all valid and proper payments made to or on behalf of the Contractor under the Construction Contract. § 14.2 Construction Contract The agreement between the Owner and Contractor identified on the cover page, including all Contract Documents and changes made to the agreement and the Contract Documents. § 14.3 Contractor Default. Failure of the Contactor, which has not been remedied or waived, to perform or otherwise to comply with a material term of the Construction Contract. § 14.4 Owner Default Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contact or to perform and complete or comply with the other material terms of the Construction Contact. § 14.5 Contract Documents. All the documents that comprise the agreement between the Owner and Contactor. § 15 If this Bond is issued for an agreement between a Contactor and subcontractor, the term Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. AIA Document A412- —2010. The American Institute of ArchAects. § 16 Modifications to this bond are as follows: (.Space is provided below for additional.signatures of added parties, other than those appearing on the cover page) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Signature: Name and Title: , Address: AIA Document A312TM — 2010. The American Institute of Architects. Signature: Name and Title: , Attomey4n-Fact Address: 4 :107404AIA Document A312 TM -2010 Payment Bond CONTRACTOR: (Name, legal status and address) FEDERAL SIGNAL CORPORATION 2645 Federal Signal Drive University Park, IL 60484 OWNER: (Name, legal status and address) KODIAK ISLAND BOROUGH 710 Mill Bay Road Kodiak, AK 99615 CONSTRUCTION CONTRACT Dale: 5/13/20 Bond No. 285063384 SURETY: (Name, legal status and principal place of business) LIBERTY MUTUAL INSURANCE COMPANY 175 Berkeley Street Boston, MA 02116 Amount: Five Hundred Eighteen Thousand Two Hundred Forty One and 54/100 Dollars ($ 518,241.54) Description: (Name and location) Outdoor Warning Siren System Replacement for Kodiak Island Borough, Contract No. FY2020-34. BOND Date: 5/18/20 (Not earlier than Construction Contract Date) Five Hundred Eighteen Thousand Two Hundred Forty One and 54/100 Dollars Amount: ($ 518,241.54) Modifications to this Bond: 0 None ❑ See Section 18 CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) FEDERAL SIGZCPORATIONLIBERTY MUTUAL INSURANCECOMPANYYSignature:14� Signature:Name Name Susan A. Welsh, Attomey4n-Fact and Title: (�' 9yZSJ� and Title: (Any addiitana7 siIA tures`bpp>�on the last page ojthis Payment Bond.) (FOR INFORMATION ONLY— Name, address and telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE: AON RISK SERVICES CENTRAL, INC. (Architect, Engineer or other party:) 200 E. Randolph 12th Floor Chicago, IL 60661 This document has Important legal consequences. Consultation with an attorney Is encouraged with respect to its completion or modification. Any singular reference to Contractor, Surely, Owner or other party shall be considered plural where applicable. AIA Document A312-2010 combines two separate bonds, a Performance Bond and a Payment Bond, Into one form. This is not a single combined Performance and Payment Bond. § 1 The Contractor and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner to pay for labor, materials and equipment furnished for use in the performance of the Construction Contract, which is incorporated herein by reference, subject to the following terms. § 2 If the Contractor promptly makes payment of all sums due to Claimants, and defends, indemnifies and holds hardess the Owner from claims, demands, liens or suits by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract, then the Surety and the Contractor shall have no obligation under this Bond. § 3 If there is no Owner Default under the Construction Contract, the Surety's obligation to the Owner under this Bond shall arise after the Owner has promptly notified the Contractor and the Surety (at the address described in Section 13) of claims, demands, liens or suits against the Owner or the Owner's property by any person or entity seeking payment for labor, materials or equipment furnished for use in the performance of the Construction Contract and tendered defense of such claims, demands, liens or suits to the Contractor and the Surety. § 4 When the Owner has satisfied the conditions in Section 3, the Surety shall promptly and at the Surety's expense defend, indemnify and hold harmless the Owner against a duly tendered claim, demand, lien or suit. § 5 The Surety's obligations to a Claimant under this Bond shall arise after the following: § 5.1 Claimants, who do not have a direct contract with the Contractor, .1 have furnished a written notice of non-payment to the Contractor, slating with substantial accuracy the amount claimed and the name of the party to whom the materials were, or equipment was, famished or supplied or for whom the labor was done or performed, within ninety (90) days after having last performed labor or last furnished materials or equipment included in the Claim; and .2 have sent a Claim to the Surety (at the address described in Section 13). § 5.2 Claimants, who are employed by or have a direct contract with the Contractor, have sent a Claim to the Surety (at the address described in Section 13). § 6 If a notice of non-payment required by Section 5. 1.1 is given by the Owner to the Contractor, that is sufficient to satisfy a Claimant's obligation to furnish a written notice of non-payment under Section 5.1.1. § 7 When a Claimant has satisfied the conditions of Sections 5.1 or 5.2, whichever is applicable, the Surety shall promptly and at the Surety's expense take the following actions: § 7.1 Send an answer to the Claimant, with a copy to the Owner, within sixty (60) days after receipt of the Claim, staling the amounts that are undisputed and time basis for challenging any amounts (hat are disputed; and § 7.2 Pay or arrange for payment of any undisputed amounts § 7.3 The Surety's failure to discharge its obligations under Section 7.1 or Section 7.2 shall not be deemed to constitute a waiver of defenses the Surety or Contractor may have or acquire as to a Claim, except as to undisputed amounts for which die Surety and Claimant have reached agreement. If, however, the Surety fails to discharge its obligations under Section 7.1 or Section 7.2, the Surety shall indemnify the Claimant for the reasonable attorney's fees the Claimant incurs thereafter to recover any sums found to be due and owing to the Claimant. § 8 The Surety's total obligation stall not exceed the amount of this Bond, plus the amount of reasonable attorney's fees provided under Section 7.3, and ttme amount of this Bond shall be credited for any payments made in good faith by the Surety. § 9 Amounts owed by the Owner to the Contractor under the Construction Contract shall be used for the performance of the Construction Contract and to satisfy claims, if any, under any constrction performance bond. By the Contractor furnishing and the Owner accepting this Bond, they agree that all funds earned by the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and Surety under this Bond, subject to the Owner's priority to use the funds for the completion of the work. AIA Document A312TM — 2010. The American I ntlitute of Archheds. § 10 The Surety shall not be liable to the Owner, Claimants or others for obligations of the Contractor that are unrelated to the Construction Contract. The Owner shall not be liable for the payment of any costs or expenses of any Claimant under this Bond, and shall have under this Bond no obligation to make payments to, or give notice on behalf of, Claimants or otherwise have any obligations to Claimants under this Bond. § 11 The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. § 12 No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the state in which the project that is the subject of the Construction Contract is located or after the expiration of one year from the date (1) on which the Claimant sent a Claim to the Surety pursuant to Section 5.1.2 or 5.2, or (2) on which the last labor or service was performed by anyone or the last materials or equipment were famished by anyone under the Construction Contract, whichever of (1) or (2) first occurs. If the provisions of this Pamgmph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. § 13 Notice and Claims to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the page on which their signature appears. Actual receipt of notice or Claims, however accomplished, shall be sufficient compliance as of the date received. § 14 When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. When so furnished, the intent is that this Bond shall be construed as a statutory bond and not as a common law bond. § 15 Upon request by any person or entity appearing to be a potential beneficiary of this Bond, the Contractor and Owner shall promptly famish a copy of this Bond or shall permit a copy to be made. § 16 Definitions § 16.1 Claim. A written statement by the Claimant including at a minimum: .1 the name of the Claimant; .2 die name of the person for whom the labor was done, or materials or equipment furnished; .3 a copy of the agreement or purchase order pursuant to which labor, materials or equipment was famished for use in the performance of the Construction Contract; .4 a brief description of the labor, materials or equipment furnished; .5 the date on which the Claimant last performed labor or last furnished materials or equipment for use in the performance of the Construction Contract; .6 the total amount earned by the Claimant for labor, materials or equipment furnished as of the date of the Claim; .7 the total amount of previous payments received by the Claimant; and .8 the total amount due and unpaid to the Claimant for labor, materials or equipment furnished as of the date of the Claim. § 16.2 Claimant. An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to furnish labor, materials or equipment for use in the performance of the Construction Contract. The tern Claimant also includes any individual or entity that has rightfully asserted a claim under an applicable mechanic's lien or similar statute against the real property upon which the Project is located. The intent of this Bond shall be to include without limitation in the terns "labor, materials or equipment' that part of water, gas, power, fight, heat, oil, gasoline, telephone service or rental equipment used in the Construction Contract, architectural and engineering services required for performance of the work of the Contractor and the Contractor's subcontractors, and all other items for which a mechanic's lien may be asserted in the jurisdiction where the labor, materials or equipment were furnished. § 16.3 Construction Contract The agreement between die Owner and Contractor identified on the cover page, including all Contract Documents and all changes made to the agreement and the Contract Documents. AIA Document A312- —2010. The American Institute of Archkeds. § 16.4 Owner Default Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract § 16.5 Contract Documents. All the documents that comprise the agreement between the Owner and Contractor. § 17 If this Bond is issued for an agreement between a Contractor and subcontractor, the tern Contractor in this Bond shall be deemed to be Subcontractor and the term Owner shall be deemed to be Contractor. § 18 Modifications to this bond are as follows (Space it provided below for additional signatures of addedparties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Signature: Name and Title: Address: AIA Document A312- —2010. The American Institute of AmhAeds. Signature: Name and Tide: , Amomey-in-Fad Address: This Power of Attorney limits the acts of those named herein, and they have no authority to 10� bind the Company except in the manner and to the extent herein staled. Libert —yLiberty Mutual Insurance Company Mutual. The Ohio Casualty Insurance Company Certificate No: 6202968-285057 SURETY West American Insurance Company POWER OF ATTORNEY KNOWN ALL PERSONS BY THESE PRESENTS: That The Ohio Casualty Insurance Company is a corporation duly organized under the laws of the Slate of New Hampshire, that Liberty Mutual Insurance Company is a corporation duly organized under the laws of the State of Massachusetts, and West American Insurance Company is a corporation duly organized under the laws of the State of Indiana (herein collectively called the'Companies"), pursuant to and by authority herein set forth, does hereby name, Constitute and appoint, Judy A. Andersen; Samantha Chierici; Jessica B. Dempsey; Debra J. Doyle; Kristin L. Hannigan; Jennifer L. Jakaitis; Judith A. Lucky-Eftimor James B. McTag art• Sandra M. Nowak; Diane M. O'Leary; Christina L. Sandoval; Susan A. Welsh; Sending M. Winsted all of the city of Chicago state of IL each individually if there be more than one named, its We and lawful attomey-in-fact to make, execute, seal, acknowledge and deliver, for and on its behalf as surety and as its act and deed, any and all undertakings, bonds, recognizences and other surety obligations, in pursuance of these presents and shall be as binding upon the Companies as if they have been duly signed by the president and attested by the secretary of the Companies in their own proper persons. IN WITNESS WHEREOF, this Power of Attorney has been subscribed by an authorized officer or official of the Companies and the corporate seals of the Companies have been affixed thereto this 17th day of January 1 2020 . Slate of PENNSYLVANIA County of MONTGOMERY ss Liberty Mutual Insurance Company The O /hionC asualty Insurance Company West American Insurance Company By: J/( David M. Carey, Assistanl5acrelary On this 17th day of January , 2020 before me personally appeared David M. Carey, who acknowledged himself to be the Assistant Secretary of Liberty Mutual Insurance m Company, The Ohio Casualty Company, and West American Insurance Company, and that he, as such, being authorized so to do, execute the foregoing instrument for the purposes therein contained by signing on behalf of the corporations by himself as a duly authorized officer. m IN WITNESS WHEREOF, I have hereunto subscribed my name and affixed my notarial seal at King of Prussia, Pennsylvania, on the day and year first above written. .N PA Q��yonw fS�TF( COMMONWEALTH OF PENNSYLVANIA A FW Y= y Notarial Neel y OF Teresa Pestp.,Montgo Montgomery Public Upper Merssion E ,Montgomery County By: My Cammbsbn Expires March 29, 2021 Men,baG Ponnsylvanb AffeGaWOn of NaleMe eresa Pastella, Notary Public '« This Power of Attorney is made and executed pursuant to and by authority of the following By-laws and Authorizations of The Ohio Casualty Insurance Company, Liberty Mutual Insurance Company, and West American Insurance Company which resolutions are now in full force and effect reading as follows: ARTICLE IV - OFFICERS: Section 12. Power of Attorney. m Any officer or other official of the Corporation authorized for that purpose in writing by the Chairman or the President, and subject to such limitation as the Chairman or the President may prescdbe, shall appoint such atlomeys-in-fact, as may be necessary to act in behalf of the Corporation to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Such aftomeys-in-fact, subject to the limitations set forth in their respective pourers of aftomey, shall have full power to bind the Corporation by their signature and execution of any such instruments and to attach thereto the seal of the Corporation. When so executed, such instruments shall be as binding as if signed by the President and attested to by the Secretary. Any power or authority granted to any representative or attomey-in-fact under the provisions of this article may be revoked at any time by the Board, the Chairman, the President or by the officer or officers granting such power or authority. ARTICLE XIII -Execution of Contracts: Section 5. Surety Bonds and Undertakings. Any officer of the Company authorized for that purpose in writing by the chairman or the president, and subject to such limitations as the chairman or the president may prescribe, shall appoint such aftomeys-in-fact, as may be necessary to act in behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Such aftomeys-in-fact subject to the limitations set forth in their respective powers of attorney, shall have full power to bind the Company by their signature and execution of any such instruments and to attach thereto the seal of the Company. When so executed such instruments shall be as binding as if signed by the president and attested by the secretary. Certificate of Designation - The President of the Company, acting pursuant to the Bylaws of the Company, authorizes David M. Carey, Assistant Secretary to appoint such aftomeys-in- fact as may be necessary to act on behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizamces and other surety obligations. Authorization - By unanimous consent of the Company's Board of Directors, the Company consents that facsimile or mechanically reproduced signature of any assistant secretary of the Company, wherever appealing upon a certified copy of any power of attorney issued by the Company in connection With surety bonds, shall be valid and binding upon the Company with the same force and effect as though manually affixed. I, Renee C. Llewellyn, the undersigned, Assistant Secretary, The Ohio Casualty Insurance Company, Ubedy Mutual Insurance Company, and West American Insurance Company do hereby certily that the original pourer of attorney of which the foregoing is a full, true and correct copy of the Power of Attorney executed by said Companies, is in full force and effect and has not been revoked. 44 - IN TESTIMONY WHEREOF, I have hereunto set my hand and affixed the seals of said Companies this 8 day of 2i2d '�D.lC. GOG INayy� 1NSU/�oear6'Pgyn`P°°aeotyr 'JC+¢3 b mA,m_19�oa 1991 0;r�a Yy,� °x Aa,+D By: Renee C. Llewellyn, Assistant Secretary LMS -12873 LMIC OCIC WAIC Mufti Co 12H8 CZ 0 H W CD f7 C l0 E W rig FEDERAL SIGNAL Quotation Safety and Security Systems Quote Number: SYSQ3153-01 Quote Date: 5/7/2020 Protecting people and our planet Expiration Date: 6/17/2020 USA : Federal Signal Drive, University Park, IRinols, 60484 I Tel +1 708 534 4756 UK : Silk House, Park Green, Macclesfield Cheshire SK117NA. I Tel +44 (0)1625 fib 66 00 QUOTED viviv .1ads[p.mm Sales Rep Company: To: Bruce Ross Kodiak Island Borough Mike Tvenge Western Regional Sales Manager 710 Mill Road 907-466-8065 Room 114 mtvenge@city.kodiak.ak.us Phone 858-264-8568 Kodiak, AK 99615 Email bross@federalsignal.mm USA Prepared By Glenn Wayman Application Engineering Manager Phone 708-587-3195 Email gwayman@fedsig.com Notes: NET 30 With Account A oval Ex -Works Universa Park IL = 0 in Kodiak Island Borough Warning System 1 8 2 1 3 2 4 11 5 77 6 11 7 44 8 11 Field Equipment MOD8032B Omnl-Directional Electronic Siren, 124dB @ 100fV3Bm. MOD5020B Omnl-Directlonal Electronic Siren, 120dB @ 00fV30m. MOD4016B Omni-Direcdonal Electronic Siren, 118dB @ 100ft/30m. UVTDU 120VAC, UHF UkraVoice Siren Controller UV400 UV Amplifier, 400W. DVSD 15500007A-05 AMB -P 9 11 OMNI -4 Digital voice mini SD mrd Battery sealed GEL 980 (MK Battery BG31) Pole Mount Antenna Bracket ANTENNA, 152-156MHZ VHF SubTotal $14,789.60 $10,374.40 $8,636.00 $5,193.60 $594.40 $260.80 $352 00 $108.00 $321.60 $110,316.80 $10,374.40 $17,272.00 $57,129.60 $45,768.80 $2,868.80 $15,488.00 $1,188.00 $3,537.60 $271,944.00 This quotation is expressly subject to acceptance by Buyer of all terms stated on this and Federal Signal's terms of sale (available on request). Any exception to or modifications of such terns shall not be binding on Seller unless expressly accepted In writing by an authorized agent or office of Seller. Any order submitted to Seller on the basis set forth above, in whola or in part, shall constitute an acceptance by Buyer of Federal Signal's terms. Any such order shall be subject to acceptance by Seller In Its discretion. Prices Subject To Change - Prices Based Upon Total Purchase - All Delivery, Training Or Consulting Services To Be Billed At Published Rates For Each Activity Involved, We Shall Not Be Liable For Any Loss Of Profits, Business, Goodwill, Data, Interrupban Of Business, Nor Fcr Incidental Or Consequential Merchantability Or Fitness Of Purpose, Damages Related To This Agreement. Quote Number: SYSQ3153-01 Page 1 of 11 0 LN MY Part Number Description Unit Price Extended Price Non -Material Items 10 1 FREIGHTANS Shipping & Handling Fees - GROUND Only $13,597.20 $13,597.20 11 1 ES-PERFBOND Performance Bond $3,807.22 $3,807.22 12 1 TK-10{RTPAY-CU ADMIN FEE -Prevailing Wage/Certified Payroll/Davis-Bacon Act. $1,199.00 $1,199.00 13 1 TK-IO-CRTPAY-CU ADMIN FEE for 1% Notice of Work fee paid to Alaska DOL based on $5,000.00 $5,00D.00 project price 14 1 TK-10-CUSTINS Installation, Commissioning and OpUmlzabon of eleven(11) $233,105.88 $233,105.88 Omni-Dlrectlonal siren systems SubTotal $256,709.30 Kodiak Island Borough System Running $528,653.30 SubTotal 15 -1 ES -Discount Project Discount provided by Federal Signal 8 both City of Kodiak and the $10,411.76 -$10,411.76 Kodiak Island Borough projects are awarded and Installed together Running SubTotal with Installation $518,241.54 discount when both projects contracts are awarded Subtotal $516,241.54 Tax $0.00 Satellite Services This quotation is expressly subject to acceptance by Buyer of all terms stated on this and Federal Signal's terms of sale (available on request). Any exception to or modifications of Such terms shall not be binding on Seller unless expressly accepted In writing by an authorized agent or office of Seller. Any order submitted to Seller on the basis set forth above, in whole or in part, shall constitute an acceptance by Buyer of Federal Signal's terms. Any such order shall be subject to acceptance by Seller in Its discretion. Prices Subject To Change - Prices Based Upon Total Purchase - All Delivery, Training Or Consulting Services To Be Billed At Published Rates For Each Activity Involved, We Shall Not Be Liable For Any Loss Of Profits, Business, Goodwill, Data, Interruption Of Business, Nor For Incidental Or Consequential Merchantability Or Fitness Of Purpose, Damages Related To This Agreement. Quote Number: SYSQ3153-01 Page 2 of 11 Part Number 'i Description ;RFTIT-� Recommended Spares 16 8 K8570063A 100W Speaker Drivers (Optional) $216.00 $1,728.00 17 1 Q860000236 UV Battery Charger, 24VDC. (Optional) $703.00 5703.00 18 1 Q2005698D PCBA, UV+ Controller. (Optional) $1,764.00 $1,764.00 19 2 Q-UV400 40OW UV Amplifier Assembly Service Part (Optional) $773.00 $1,546.00 20 2 Q8599A178A Desiccant Kit (Optional) $81.00 $162.00 21 1 Q8549A193A AC Lightning Protection (Optional) $122.00 $122.00 22 1 Q14BA147A 200 Amp Buss Fuse (Optional) $68.00 $68.00 Satellite Services This quotation is expressly subject to acceptance by Buyer of all terms stated on this and Federal Signal's terms of sale (available on request). Any exception to or modifications of Such terms shall not be binding on Seller unless expressly accepted In writing by an authorized agent or office of Seller. Any order submitted to Seller on the basis set forth above, in whole or in part, shall constitute an acceptance by Buyer of Federal Signal's terms. Any such order shall be subject to acceptance by Seller in Its discretion. Prices Subject To Change - Prices Based Upon Total Purchase - All Delivery, Training Or Consulting Services To Be Billed At Published Rates For Each Activity Involved, We Shall Not Be Liable For Any Loss Of Profits, Business, Goodwill, Data, Interruption Of Business, Nor For Incidental Or Consequential Merchantability Or Fitness Of Purpose, Damages Related To This Agreement. Quote Number: SYSQ3153-01 Page 2 of 11 . LN- Qty-- Part Number Description 0"onal Items Unit Price Extended Price Please note In order for KIB to utilize satellite services City of Kodiak must permit TCP/IP connection into Satellite network from Police Station 23 1 FS-ISAT-SITE Satellite Activation Fee, charged per unit (Optional) $40.00 $40.00 24 I FS-ISAT-SRVC Annual Satellite Service Plan, charged per UV siren controller satellite unit $460.80 $460.80 (Optional) Recurring annual fee per Satellite Unit purchased 2S 1 FS-ISAT-SITE Satellite IDP Group Fee, charged monthly (Optional) $40.00 $40.00 Recurring monthly Fee Siren Controller Satellite Equipment 26 1 Q-UV-ISAT2 UV Satellite Kit, one required per UV siren controller (Optional) $1,660.00 51,660.00 CommanderOne-Cloud Software 27 1 COMMANDER) -S COMMANDERONE ANNUAL SUB STANDARD (Optional) $5,000.00 $5,000.00 Recurring yearly fee Supplemental Charging Solar Kit-Orl Siren Location Please note, solar kit Is only Intended for supplemental charging ONLY. Solar kit Is NOT intended for use as primary means of battery charging. Plese note, the quantity of supplemental solar kits is unknown, therefore pricing for supply and install of orl kit will be listed. 28 1 PVS240W-24 Supplemental solar kit (Optional) $3,400.00 $3,400.00 29 1 TK-10-CUSfINS Installation of one(1) solar kit (Optional) $1,725.00 $1,725.00 Optional 316ss Enclosure-One(1) Siren Location SMV for Stainless Steel is charged per siren controller 30 1 ES-SMV-316SS Special Model Variation for 316 Stainless Steel Enclosures (Optional) $3,587.00 $3,587.00 Lead Time: 8-10 weeks from approvals This quotation is expressly subject to acceptance by Buyer of all terms stated on this and Federal Signal's terms or sale (available on request). Any exception to or modifications of such terms shall not be binding on Seller unless expressly accepted In writing by an authorized agent or office of Seller. Any order submitted to Seller on the basis set forth above, In whole or In part, shall constitute an acceptance by Buyer of Federal Signal's terms. Any such order shall be subject to acceptance by Seller in Its discretion. Prices Subject To Change - Prices Based Upon Total Purchase - All Delivery, Training Or Consulting Services To Be Billed At Published Rates For Each Activity Involved. We Shall Not Be Liable For Any loss Of Profits, Business, Goodwill, Data, Interruption Of Business, Nor For Incidental Or Consequential Merchantability Or Fitness Of Purpose, Damages Related To This Agreement. Quote Number: SYSQ31S3-01 Page 3 of 11 Quote Approved By: Closing Notes: Taxes Prices do not include taxes. Buyer shall pay Seller, in addition to the price of the goods, any applicable excise, sales, use or other tax (however designated) imposed upon the sale, production, delivery or use of the Goods or Services ordered to the extent required or not forbidden by law to be collected by Seller from Buyer, whether or not so collected at the time of the sale, unless valid exemption certificates acceptable to the taxing authorities are furnished to Seller before the date of invoice. Cancellation Schedule - Material: -Percentages shown are of total order value with weeks representing number of weeks from receipt of official order: 10% after 2 weeks. 20% after 4 weeks. 40% after 6 weeks. 80% after 8 weeks. Cancellation Schedule - Services: -If any cancellation of scheduled service visit occurs, Federal Signal reserves the right to impose cancellation charges as follows: -Cancellation of visit within 7 days of mobilization - 50% of agreed upon labor and incurred expenses plus handling fee. -Cancellation of visit within 2 days of mobilization - 100% of agreed upon labor and incurred expenses plus handling fee. Delivery Schedule: -From receipt of official purchase order, delivery is based upon the agreed upon schedule. Production does not commence until receipt of approved drawings to Code B(approved with comments) Warranty/Guarantee: Please see Federal Signal Limited Warranty Terms and Conditions document (attached) Storage Charges: -0.5% storage charge per ni onto I un t of invoice applies if product is not pickup/shipped within o w ks after signed FAT. Quote Approved By: Date: �Q�\S�NDeo�O t�/� This quotation is expressly subject to acceptance by Buyer of all terms stated on this and Federal Signal's terms of sale (available 'Y to or modifications of such terms shall not be binding on Seller unless expressly accepted in writing by an authorized agent or office of Scllcr. , ed to Seller on the basis get forth above, In whole or In part, shall constitute an acceptance by Buyer of Federal Signal's terms. Any such order shall be su=:ret to acceptance by Seller In Its discretion. Prices Subject To Change - Prices Based Upon Total Purchase - All Delivery, Training Or Consulting Services To Be Billed At Published Rates For Each Activity Involved. We Shall Not Be Liable For Any Loss Of Profits, Business, Goodwill, Data, Interruption Of Business, Nor For Incidental Or Consequential Merchantability Or Fitness Of Purpose, Damages Related To This Agreement. Quote Number: SYSQ31S3-03 Page 4 of 11 FEDERAL SIGNAL 2645 Federal Signal Drive U ■ niversity Park, Illinois 60484-3167 Safety and Security Systems 708-534-3400 Protecting people and our planet fedsig.com LIMITED WARRANTY TERMS AND CONDITIONS Effective January 13, 2020 Federal Signal Corporation ("Federal Signal"), subject to the terms, conditions and exceptions contained herein, warrants each NEW product to be free from defects in material and workmanship, under normal and proper use, care, maintenance and required service only. Start of Warranty, Warranty periods and exceptions to the foregoing Limited Warranty are contained on the Schedule of Products included in this document, and are subject to change at the sole discretion of Federal Signal. SPECIFIC EXCLUSIONS AND EXCEPTIONS This Limited Warrantydoes NOT apply nor is it extended to products that are not manufactured by Federal Signal. These products may be covered by a separate limited warranty provided by the particular manufacturer and all claims and questions regarding the same are to be directed to the particular manufacturer. Goods sourced by Seller from a third party for resale to Buyer shall carry only the warranty extended by the original manufacturer. Domes, lenses, lamps and batteries installed on Federal Signal products are specifically excluded. Repair or replacement of any pro- ducts) or part(s) under this warranty does NOT extend the term of this warranty, and such product(s) or part(5) shall remain covered by the unexpired portion of the warranty period or for ninety (90) days from the date of return to Federal Signal, whichever is later. This limited warranty applies ONLY to the initial or first installation of the product. This limited warranty shall not apply to products (1) that have been subjected to neglect, abuse, misuse, improper installation, inadequate maintenance, or damage due to improper use of cleaning or cleaning materials or chemicals, or non-compliance with Federal Signal's storage, installation, operation, maintenance or environmental requirements; (2) that have undergone any modi- fication or repair not previously authorized by Federal Signal in writing, or service, repair or modification by or from any facility other than an authorized Federal Signal service center or technician, or that use non -authorized software or spare or replacement parts; or (3) that fail due to reasonable and normal use or wear and tear, or materials made, furnished or specified by the Buyer or end user. During the aforesaid warranty period, Federal Signal will, at its sole option, repair or replace the products) or particular part(s) that are found to be defective in either material or workmanship, or refund the purchase price for such product(s) or part(s), which are returned or delivered, transport or shipping prepaid by the Buyer or end user, to either Federal Signal or its designated and authorized warranty service center. This limited warranty does not cover travel expenses, the cost of specialized equipment for gaining access to the product(s) or part(s), or labor charges for removal and reinstal- lation of the product. No person or affiliated company representative is authorized to alter the terms of this warranty, to give any other warranties, to extend the term or duration of this warranty, or to assume any other liability on behalf of Federal Signal in connection with the sale, servicing or repair of any product manufactured by the Federal Signal. Federal Signal reserves the right to make design changes and improvements in its products without imposing any obligation upon itself to change or improve previously manufactured products. The use in the product of any part other than parts approved by Federal Signal may invalidate this warranty. Federal Signal reserves the right to deter- mine, in its sole discretion, if the use of non -approved parts invalidates this warranty. THIS WARRANTY IS IN LIEU OF ALL OTHER WARRANTIES, EXPRESS OR IMPLIED, INCLUDING, WITHOUT LIMITATION, WARRANTIES OF MERCHANT- ABILITY AND FITNESS FOR A PARTICULAR PURPOSE, AND REGARDLESS OF ANY FAILURE OF ESSENTIAL PURPOSE. ALL OTHER WARRANTIES OF WHATSOEVER KIND AND NATURE, WHETHER EXISTING IN CONTRACT OR AT LAW, ARE HEREBY AND FOREVER DISCLAIMED. UNDER NO CIkCUMSTANCES WILL FEDERAL SIGNAL BE LIABLE OR RESPONSIBLE FOR SPECIAL, COMPENSATORY, INCIDENTAL, CONSEQUENTIAL OR PUNITIVE DAMAGES, LOST PROFITS, LOST SALES, OR L05S OF USE OR LOSS OF BUSINESS OPPORTUNITY BY OR THROUGH THE USE OF THE PRODUCT. FEDERAL SIGNAL'S SOLE AND MAXIMUM LIABILITY WITH RESPECT TO THE PRODUCT, OTHER THAN ITS OBLIGATIONS SET FORTH ABOVE, SHALL BE THE TOTAL PURCHASE PRICE PAID FOR THE PRODUCT. Revision A effective January 13, 2020 Page 5 of 11 LIMITED WARRANTY — Schedule of Products LIMITED WARRANTY—schedule of products Effective January 13, 2020 Revision A effective January 13, 2020 Page 6 of 11 Warranty Period for Parts replacement from the Warranty period for Factory date of manufacture Labor from the date of delivery stamped on the product to the first user -purchaser eakers 2 years 1 year atinum 3000 Series I 5 years 5 years thfinder 5 years 5 years LED PRODUCTS All LED (Light Emitting Diode) products unless 5 years 5 years otherwise noted 5 years 5 years LED rotating light assemblies from all light bars and beacons 3 years 3 years MicroPulse LED lights 3 years 3 years MBI LED Message Board 2 years 2 years Commander Series Flex 3 years 3 years COM550 42005 3 years 3 years STROBE PRODUCTS Strobe flash tubes 1 year 1 year 951 strobe beacons 5 years 1 year 651/851 strobe beacons 5 years 1 year _ U55, USS, and U57 UltraStar 5 years 1 year OTHER PRODUCTS Halogen Rotating Light assemblies from all light 5 years 1 year bars 5 years 1 year All halogen rotating beacons and mini -light bars, except Sentinel 5 year warranty on LED components 5 year warranty on LED components Littlite Map lights Limited lifetime warranty on Limited lifetime warranty mechanical components on mechanical components SWM Interceptor Switch Modules 1 year 1 year CAM Reverse Camera/Monitor Systems 3 years 3_years Stinger Spike Systems 5 years 5 years _PBX Series 3 years 3 years Perimeter Light Programmer 1 year 1 year DOT Flasher 3 years 3 years Atkinson Dynamics Intercoms 2 years 1 year Note: Domes, lenses, lamps, and batteries are NOT covered under warranty. Revision A effective January 13, 2020 Page 6 of 11 LIMITED WARRANTY — Schedule of Products Federal Signal Corporation - Integrated Systems Division Revision A effective January 13, 2020 Page 7 of 11 WARRANTY PERIOD FOR PARTS REPLACEMENTAND FACTORY PERFORMED LABOR" Mechanical Sirens 5 years parts and labor from date of delivery, return to factory for service 2001-130 1 508-1 28 1 Equinox Eclipse8 / Model 2 ELECTRONIC SIRENS MOD1004B / MOD2008B / MOD3012B 2 years parts and labor from date of delivery, return to factory for service MOD4016B / MOD5020B / MOD60248 MOD80328 DSA2/3/4/5/6 CONTROLLERS 552000+ FC Controllers DCFCTBD Controllers 2 years parts and labor from date of delivery, return to factory for service UV / UVRI/UVIC Controllers SIGNALING DEVICES Beacons / Speakers / Sounders 5 years parts and labor from date of delivery, return to factory for service ECHO Intercoms SelecTone Controllers AudioMaster products Atkinson products MISCELLANEOUS 2 years parts and labor from date of delivery, return to factory for service IF Informers / Radio Informers 1 year parts and labor from date of delivery, return to factory for service SignalTech —Beacons Sounders, Strobes FT400BX OEM PRODUCTS PC Equipment Field Devices Security and LPR products Federal Signal utilizes the original manufacturer's warranty UPS systems PABX Systems PAGA 18 months from shipment or 12 months from commissioning/system field acceptance whichever is sooner covering parts and labor, return to factory for service. SOFTWARE Commander (SFCD-XX) Free from defects for 12 months from date of acceptance, Software Maintenance Agreements SmartMsg available 'Federal Signal Offers extended warranties and software maintenance agreements —contact Federal Signal for further information "On-site services not included •• Domes, lenses, lamps and batteries installed on Federal Signal products are specifically excluded When Federal Signal has provided a turn -key installation including optimization and/or commissioning services, Federal Signal will provide onsite warranty service during the first 60 -days after completion of the installation. Revision A effective January 13, 2020 Page 7 of 11 rFEDERAL SIGNAL Protecting people and our planer TERMS AND CONDITIONS OF SALE (Goods and Services) Effective 3-10-2020 1. DEFINITIONS. In these Terms and Conditions of Sale, "Seller" means Federal Signal Corporation, Including any division or subsidiary of Federal Signal Corporation; "Buyer' means the person or entity that placed the order or on whose behalf the order Is placed; "Goods" means the goods Identified in Sellers acknowledgement of Buyer's order; "Services" means the services identified in Sellers acknowledgment of Buyers order; "Contract" means the written agreement (which shall Include these Terms and Conditions) between Buyer and Seller for the supply of the Goods and/or provision of Services; and "Contract Price" means the price payable to Seller by Buyer for the Goods and/or Services. 2. ORDERS; CONTRACT. All orders must be In writing. Buyer understands and agrees that any order, upon Acceptance by Seller, shall be subject to these Terms and Conditions of Sale. Seller objects to and shall not be bound by any additional or different terms, whether printed or otherwise, in Buyers order or in any other communication from Buyer to Seller, or any trade usage or course of dealing between Buyer and Seller, unless expressly agreed to in writing by Seller in Sellers acknowledgement of Buyer's order. If the details of the Goods or Services described in Sellers quotation differ from those set out in Seflers acknowledgment, the latter shall apply. Seller reserves the right to make minor modifications and/or improvements to the Goods before delivery provided that the performance of the Goods is not adversely affected and that neither the Contract Price nor the delivery dale Is affected. 3. EFFECTIVE DATE; CANCELLATION. The Contract shall become effective only upon the dale of acceptance of Buyers order by Sellers written acknowledgement or upon Sellers commencement of performance, whichever is first ("Acceptance"). Buyer may not cancel or change an order after Acceptance by Seller without the written consent of Seller. Notwithstanding the forgoing. Seller may, In Its sale discretion, agree to a written request from Buyer for cancellation of an open order under the following conditions: Buyer shall be subject to cancellation charges equal to the greater of (I) 110% of the cost of work completed and/or custom materials purchased at the time the request Is delivered, or (II) a percentage of the canceled portion of the Contract calculated as follows: Cancellation Schedule — Material 10% - if cancelled more than 2 weeks from the Effective Dale; 20% - if cancelled more than 4 weeks from the Effective Date; 40% - if cancelled more than 6 weeks from the Effective Date; 80% - If cancelled more than 6 weeks from the Effective Date. Cancellation Schedule - Services: If services are cancelled within 1 week of the scheduled mobilization date; 110% of unrecoverable out-of-pocket costs + 50% of scheduled services will be charged If services are cancelled within 2 days of the scheduled mobilization dale; 110% of unrecoverable out-of-pocket costs + 100% of scheduled services will be charged 4. PRICE AND PAYMENT TERMS. Unless previously withdrawn, Sellers quotation Is open for acceptance within the period staled therein or, when no period Is so stated, within thirty days after its date of issuance to Buyer. Prices are subject to Increase by Seller based on Sellers prices in effect at the time of shipment In all instances where the specified shipment date is more than 30 days from the date of the order from Buyer. Unless otherwise specified in the Contract or Sellers applicable price list, prices are FOB Seller's point of shipment, and the terms of payment are NET 30 days from the date of Invoice. Amounts not paid when due shall bear interest for each day after the due date calculated at the annual rate of 18% or the highest rate permitted by law, whichever is less. Freight, packing and handling will be charged at Seller's standard rates, which are available upon request by Buyer. If the Contract is for more than one unit of Goods, the Goods may be shipped In a single lot or in several lots at the discretion of Seller. In such event, each such shipment shall be paid separately and Buyer shall be responsible for all transportation charges. Seller may require full or partial payment or payment guarantee in advance of shipment whenever, in its opinion, the financial condition of Buyer so warrants. Payment by credit card may be subject to a service charge. S. TITLE; RISK OF LOSS. Tifle to, ownership of, and risk of loss or damage to the Goods shall pass to the Buyer, and Buyer shall be responsible for insurance of the Goods, upon delivery of the Goods to the carrier. Alternatively, If It Is expressly stated in the Contract that Seller is to procure Insurance for the Goods after delivery to the carrier, such insurance will be charged at the carriers standard rates. "FOB" and any other delivery term used in the Contract shall be defined In accordance with the latest version of Incoterms. Buyer shall have sole responsibility for processing and collection of any claim of loss against the carder. 6. TAXES. Prices do not include taxes. Buyer shall pay Seller, in addition to the price of the goods, any applicable excise, sales, use or other tax (however designated) Imposed upon the sale, production, delivery or use of the Goods or Services ordered to the extent required or not forbidden by law to be collected by Seller from Buyer, whether or not so collected at the time of the sale, unless valid exemption certificates acceptable to the taxing authorities are furnished to Seller before the date of invoice. 7. DELIVERY; FORCE MAJEURE. Unless otherwise stated In Sellers quotation, all periods staled for delivery or completion run from the Effective Date and are to be treated as estimates only and are not guaranteed. If Seller Is delayed In or prevented from performing any of its obligations under the Contract due to the acts or omissions of Buyer or Its agents, the delivery/comptetion period and the Contract Price shall both be adjusted as necessary. If delivery is delayed due to any act or omission of Buyer, or If having been notified that the Goods are ready for shipment, Buyer fails to take delivery or provide adequate shipping Instructions, Seller shall be entitled to place the Goods Into storage at Buyers expense. Upon placing the Goods Into storage, delivery shall be deemed to be complete, risk In the Goods shall pass to Buyer and Buyer shall pay Seller accordingly. The Contract (other than Buyers obligation to pay all sums due to Seller In accordance with the Contract) shall be suspended, without liability, in the event and to the extent that Its performance is prevented or delayed due to any circumstance beyond the reasonable control of the party affected, including but not limited to: Act of God, war, armed conflict or terrorist attack, dot, fire, explosion, accident, flood, disease, health epidemic or pandemic, sabotage; governmental decisions or actions (Including but not limited to prohibition of exports or re-exparts or the failure to grant or the revocation of applicable export licenses), or labor trouble, strike, lockout or Injunction. Seller shall have no obligation to deliver any hardware, software, services or technology unless and until it has received any necessary licenses or authorizations or has qualified for general licenses or license exceptions under applicable import, export control and sanctions laws, regulations, orders and requirements, as they may be amended from time to time (including without limitation those of the United States, the European Union and the jurisdiction in which Seller is established or from which the Items are supplied). If for any reason any such licenses, authorizations or approvals are denied or revoked, or If there Is a change in any such applicable laws, regulations, orders or requirements that would prohibit Seller from fulling the P09gE1113bll4 Contract, or would in the reasonable Judgment of Seller otherwise expose Seller to a risk of liability under applicable laws, regulations, orders or requirements, Seller shall be relieved without liability of all obligations under the Contract. If either party Is delayed or prevented from performance of its obligations by reason of this clause for more than 160 consecutive calendar days, either party may terminate the then unperformed portion of the Contract by notice in writing given to the other party, without liability provided that Buyer shall be obliged to pay the reasonable cost and expense of any work in progress and to pay for all Goods delivered and Services performed as at the date of termination. Seller may deliver by Installments, and each delivery shall constitute a separate Contract. Failure by Seller to deliver any one or more of the Installments in accordance with their terms shall not entitle Buyer to terminate the whole Contract or treat it as repudiated. 6, INSPECTION. Buyer shall Inspect the goods immediately upon the receipt thereof. All claims for shortfalls In quantity or for incorrect delivery or for any alleged defect in Setters performance under this Contract, capable of discovery upon reasonable inspection, must be fully set forth in writing and received by Seller within five days of Buyers receipt of the Goods. Failure to make any such claim within said period shall constitute a waiver of such claim and an Irrevocable acceptance of the Goods by Buyer. 9. DEDUCTIONS AND RETURNS. Buyer must contact the factory before returning any merchandise. Goods in new, unused and undamaged condition that are resalable as new products without modification or repackaging may be returned to Seller for credit only upon the Sellers prior written consent (such consent to be In the sole discretion of Seller) and upon terms specified by Seller, Including prevailing restocking, freight, and handling charges. A Return Material Authorization (RMA) must be obtained before returning merchandise for credit. All returns are subject to Inspection of merchandise and any defects in the units will be charged back to the Buyer at the cost of parts and labor. Credit deductions will not be honored unless covered by an RMA Buyer assumes all risk of loss for such returned goods until actual receipt thereof by Seller. Agents of Seller are not authorized to accept returned goods or to grant allowances or adjustments with respect to Buyers account. i [411111111 1J 10 rf r]h'L•1it; III : Y f! NOTICE: IF ANY GOODS, INCLUDING ANY COMPONENT PART OF ANY GOODS, OR SERVICES SOLD BY SELLER ARE ACCOMPANIED BY A SEPARATE MANUFACTURER'S WARRANTY COVERING SUCH GOODS OR SERVICES, THE TERMS OF SUCH WARRANTY, INCLUDING ALL LIMITATIONS OF SUCH WARRANTY, SHALL GOVERN THOSE GOODS OR SERVICES, AND ANY WARRANTY OF SELLER OTHERWISE APPLICABLE TO SUCH GOODS OR SERVICES SHALL NOT APPLY. A. Goods. Subject to the forgoing, Sellers limited warranty for any new Goods which are the subject of any Sellers acknowledgement of Buyers order may be found at www.fedsig.com/ssg-warranty or may be obtained by writing to Federal Signal Corporation, 2645 Federal Signal Drive, University Park, IL 60464; by email to infoOfederalsional.com; or by calling 7061534.3400. B. Services Seller warrants that Services provided by Seller will be performed with all reasonable skill, care and diligence and In accordance with standard Industry practice. Seller will correct defects In Services provided by Seller and reported to Seller within ninety days after completion of such Services. Services corrected In accordance with this Section shall be subject to the foregoing warranty for an additional ninety days from the date of completion of correction of such Services. 11. REMEDIES AND LIMITATIONS OF LIABILITY. The remedies contained the preceding paragraph constitute the sole recourse against Seller for breach of any of Sellers obligations under the Contract, whether of warranty or otherwise. IN NO EVENT SHALL SELLER BE LIABLE FOR CONSEQUENTIAL DAMAGES NOR SHALL SELLER'S LIABILITY ON ANY CLAIM FOR ANY DIRECT, INCIDENTAL, CONSEQUENTIAL OR SPECIAL DAMAGES ARISING OUT OF OR CONNECTED WITH THE CONTRACT OR THE MANUFACTURE, SALE, DELIVERY OR USE OF THE GOODS OR SERVICES EXCEED THE PURCHASE PRICE OF THE GOODS OR SERVICES. The term "consequential damages" shall Include, but not be limited to, loss of anticipated profits, business Interruption, loss of use, revenue, reputation and data, costs Incurred, Including without limitation, for capital, fuel, power and loss or damage to property or equipment. It Is expressly understood that any technical advice furnished by Sellerwith respect to the use of the Goods is given without charge, and Seller assumes no obligation or liability for the advice given, or results obtained, all such advice being given and accepted at Buyers risk 12. LIMITED INDEMNITY AGAINST INFRINGEMENT. Seller shall, at Its own expense, defend any litigation resulting from sale of the Goods to the extent that such litigation alleges that the Goods or any part thereof Infringes any United Stales patent, copyright, or trademark, provided that such claim does not arise from the use of the Goods In combination with equipment or devices not made by Seller or from modification of the Goods, and further provided that Buyer notifies Seller Immediately upon Its obtaining notice of such Impending claim and cooperates fully with Seller In preparing a defense. If Buyer provides to Seller the authority, assistance, and Information Seller needs to defend or settle such claim, Seller shall pay any final award of damages In such suit and any expense Buyer incurs at Sellers written request, but Seller shall not be liable for a settlement made without Its prior written consent. If the Goods are held to be Infringing and the use thereof Is enjoined, Seller shall, at its option, either (I) procure for the Buyer the right to use the Goods, (it) replace the Goods with others which do not constitute Infringement, or (Iii) remove the Infringing Goods and refund the payment(s) made therefor by Buyer. The foregoing states the Buyers sole remedy for, and Sellers entire liability and responsibility for, infringement of any patent, trademark, or copyright relating to the Goods provided hereunder. THIS LIMITED INDEMNITY IS IN LIEU OF ANY OTHER STATUTORY OR IMPLIED WARRANTY AGAINST INFRINGEMENT. 13. INTELLECTUAL PROPERTY RIGHTS. All drawings, data, designs, tooling, equipment, procedures, engineering changes, Inventions, trade secrets, copyrights , mask works, source code, object code, patents, patent applications, know-how, computer and/or product software and all parts thereof, trademarks and all other information, technical or otherwise which was developed, made or supplied by or for Seller in the production of any Goods or Services sold hereunder will be and remain the sole property of Seller (or Its licensors, if any). Buyer agrees not to reverse engineer any Goods purchased hereunder. 14. EXPORT REGULATIONS. Buyer agrees to comply fully with all laws and regulations concerning the export of Goods from the United States 15. INSTALLATION. In those circumstances where Seller has agreed to Install Goods for Buyer, the following provisions shall control: A. Responsibility. Installation shall be by Buyer unless otherwise specifically agreed to in writing by Seller. B. Receiving Product and Staging Location. Buyer Is responsible to receive, store and protect all Goods intended for installation purposes, Including, but not exclusively, siren equipment, poles, batteries, and installation materials. Materials received In cardboard containers must be protected from all forms of precipitation. Additionally, Buyer is to provide a staging area of an appropriate size for Installation contractors to work from and to store equipment overnight. C. Installation Methods 6 Materials. Installation is based on methods and specifications intended to meet applicable safely and Installation codes and regulations. Design changes required by Buyer may result In additional charges. PBggr92rbA4 D. Radio Freauencv Interference. Seller Is not responsible for RF tmnsmisslan and reception affected by system Interference beyond its control. E. Installation Site Aporoval. Buyer must provide signed documentation to Seller, such as the "WARNING SITE SURVEY FORM" or a document with the equivalent information, that Seller is authorized to commence Installation at the site designated by Buyer before Seller will commence Installation. Once installation has started at an approved site, Buyer is responsible for all additional costs Incurred by Seller for redeployment of resources If the work is stopped by Buyer or Its agents, property owners, or as the result of any governmental authority or court order, or if it Is determined that Installation is not possible at the intended location, or the site Is changed for any reason by the Buyer. F. AC Power Hookup. Buyer is responsible to coordinate and pay for all costs to bring proper AC power to the electrical service disconnect installed adjacent to the controller cabinet, unless these services are quoted by Seller. G. Permits & Easements. Seller will obtain and pay for electrical and right-of-way work permits as necessary for Installations. Buyer is responsible for obtaining and payment of all other required easements, permits, or other fees required for Installation, unless specifically quoted. H. Soil Conditions Clause. In the event of poor site conditions Including, but not limited to rock, cave-ins, high water levels, or Inability of soil to provide stable Installation to meet specifications, Seller will direct installation contractors to attempt pole Installation for a maximum of 2 hours. Buyer approval will be sought when pole installation exceeds 2 hours and abandoned if Seller cannot obtain approval in a timely manner. I. Contaminated Sites. Seller is not responsible for cleanup and restoration of any Installation sites or Installer equipment where contaminated soil is encountered. Seller will not knowingly approve installation at any site containing contaminates. Buyer must Inform Seller when known or suspected soil contaminates exist at any intended Installation site. J. Site Cleanup. Basic Installation site cleanup includes Installation debris removal, general site cleanup, and general leveling of affected soil within 30' of the pole. Additional site restoration quotes are available. K. Waste Disposal. Buyer Is responsible for providing disposal of all parking materials Including shipping skids and containers. L. Work Hours. All installation quotes are based on the ability to work outdoors during daylight hours and Indoors from 7 AM to 7 PM Monday through Saturday. Work restrictions or limitations Imposed by Buyer or Its agents may result in additional charges being assessed to Buyer for services. M. Protect Reporting. Installation & Service Progress Reports will be provided on a regular basis, normally every week during active installation, unless pre -arranged otherwise by mutual agreement. N. Safety Reauirements & Compliance. Seller requires that all subcontractors and their employees follow applicable laws and regulations pertaining to all work performed, equipment utilized and personal protective gear common to electrical and construction site work performed In the Installation of Seller equipment. Additional safety compliance requirements by Buyer may result In additional charges assessed to Buyer for the time and expenses required to comply with the additional requirements. 1S. ASSIGNMENT AND SUBCONTRACTING. Seller may assign its rights and obligation by giving Buyer written notice thereof but without being obligated to obtain Buyers consent prior thereto. In the event of an assignment, Seller shall be discharged of any liability pursuant to those purchase orders which have been assigned or delegated. Customer may not assign Its rights nor delegate Its obligations under any or all of Its purchase orders unless Seller's written consent is obtained prior thereto and any such assignment or delegation without such consent shall be void. 17. DEFAULT, INSOLVENCY AND CANCELLATION. Seller shall be entitled, without prejudice to any other rights it may have, to cancel the Contract Immediately, In whole or in part, by notice In writing to Buyer, if (a) Buyer is in default of any of its obligations under the Contract and fails, within 20 (twenty) days of the date of Seller's notification In writing of the existence of the default, either to rectify such default if it is reasonably capable of being rectified within such period or, if the default Is not reasonably capable of being rectified within such period, to take and diligently continue action to remedy the default or (b) on the occurrence of an Insolvency Event in relation to Buyer. "Insolvency Event" in relation to Buyer means any of the following: (1) a meeting of creditors of Buyer being held or an arrangement or composition with or for the benefit of Its creditors being proposed by or in relation to Buyer; (Ii) a receiver, administrator or similar person taking possession of or being appointed over or any distress, execution or other process being levied or enforced (and not being discharged within seven days) on the whole or a material part of the assets of Buyer; (iii) Buyer ceasing to carry on business or being unable to pay Its debts; (iv) Buyer or its equity holders or the holder of a qualifying floating charge giving notice of their Intention to appoint, or making an application to the court for the appointment of, an administrator, (v) a petition being presented (and not being discharged within 30 days) or a resolution being passed or an order being made for the administration or the winding -up, bankruptcy or dissolution of Buyer; or (vi) the happening in relation to Buyer of an event analogous to any of the above in any jurisdiction in which it is Incorporated or resident or in which It cables on business or has assets. Seller shall be entitled to recover from Buyer or Buyer's representative all costs and damages Incurred by Seller as a result of such default or cancellation, including all costs of collection and a reasonable allowance for overheads and profit (including but not limited to loss of prospective profits and overheads). 18. SEVERABILITY. If any term, clause or provision contained In the sales contract is declared or held invalid by a court of competent jurisdiction, such declaration or holding shall not affect the validity of any other term, clause or provision herein contained. 19. NO WAIVER. No waiver by either party with respect to any breach or default or of any right or remedy and no course of dealing or performance, shall be deemed to constitute a continuing waiver of any other breach or default or of any other right or remedy, unless such waiver be expressed in writing and signed by the party to be bound. 20. NOTICES. All notices and claims in connection with the Contract must be In writing. 21. INTEGRATION. These terms and conditions supersede all other communications, negotiations and prior oral orwritten statements regarding the subject matter of these terms and conditions. Pa®eg103rbIl4 22. GOVERNING LAW AND LIMITATIONS. The formation and performance of the sales contract shall be governed by the laws of the State of Illinois. Venue for any proceeding Initiated as the result of any dispute between the parties that arises under this Agreement shall be either the state or federal courts In Cook or DuPage County, Illinois. Whenever a term defined by the Uniform Commercial Code as adopted In Illinois is used in these standard terms, the definition contained in said Unborn Commercial Code Is to control. Any action by the Buyer for breach of the sales contract or any covenant or warranty contained herein must be commenced within one year after the cause of action accrued. 23. U.N. CONVENTION. Pursuant to Article 6 of the United Nations Convention on Contracts for the International Sale of Goods (the "UN Convention"), the Parties agree that the UN Convention shall not apply to this Agreement. Pa@eglg 46114