Loading...
FY2026-43 KIB Admin Building Automation Services Support with LONG Building Technologies_r BUILDING AUTOMATION AGREEMENT s IMPACT— DRIVEN SERVICETM Kodiak Island Borough Borough Building 710 Mill Bay Rd Kodiak, AK 99615 December 19, 2025 d By- Trish Tor 907-315-4844 Ttorres a@LON( 0 L N G --�— IN mapom ;:- f. IMP' Quote Number: PV7858 Borough Building 710 Mill Bay Rd. Kodiak, AK 99615 Dear Patricia, December 19, 2025 Contract FY2026-43 Page 2 of 14 Page 2 of 12 N G "' Thank you for choosing LONG Building Technologies, Inc. as your Building Automation System (BAS) Support Provider. Your BAS is a vital component of your building and is essential for monitoring and controlling the operation and efficiency of your HVAC (heating, ventilation, and air-conditioning) systems. However, all technology requires upkeep to maintain performance and extend its life, and your system is no exception. Optimizing comfort, staff and tenant productivity, resource efficiency, and cost are just a few of the areas that may be impacted by these systems. As your service partner, we'll ensure these impacts are positive. Desired Outcomes for Facility via Impact -Driven Service TM 1. Proactive building maintenance 2. Energy savings 3. Equipment and controls longevity 4. Optimizing comfort Tentative Schedule: 1. Tentative Start date will be on 12/31/25 2. Tentative End date will be on 11/30/30 Yearly investment for this 1 Year Remote -Only Agreement with 4 optional years: Billed Quarterly at One Thousand Seven Hundred Eighty -One Dollars Twenty -Five Cents .........$1,781.25 Annual equivalent is $7,125 (Includes Onboarding Costs*) Includes: 2 Remote Visits and 2 Analytic Reviews per year The following agreement includes upfront costs incurred by LONG to be spread out evenly throughout the anticipated term of this agreement, billed quarterly at $630.80 for 60 months. If either party determines the necessity to terminate the agreement prior to the full-term expiration; LONG will invoice for any and all remaining costs incurred on the final invoice. Contract FY2026-43 Page 3 of 14 / . gyp. Page 1 of 2 Kodiak Island Borough Agreement Page 1 of 2 Project: Borough Building Automation Service Agreement Contract Number: FY2026-43 This CONTRACT ("Contract"), between the Kodiak Island Borough, Alaska, herein called the Borough, acting by and through its Borough Manager, and Long Building Technologies, Inc. Company Name PO Box 5501, Denver, CO 80217-5501 Company Address (Street or PO Box, State, Zip) a/an ❑ Individual ❑Partnership ❑Joint Venture ❑Sole Proprietorship ElCorporation incorporated under the laws of the State of Alaska, its successors and assigns, herein called the Contractor, is effective the date of the signature of the Borough Manager on this document. The Contractor, for and in consideration of the payment or payments herein specified and agreed to by the Borough, hereby covenants and agrees to furnish and deliver all the materials and to do and perform all the work and labor required in the construction of the above - referenced project as bid by the Contractor, which bid and prices named, together with the Contract Documents (as hereinafter defined) are made a part of this Contract and accepted as such. It is distinctly understood and agreed that no claim for additional work or materials, done or furnished by the Contractor and not specifically herein provided for, will be allowed by the Borough, nor shall the Contractor do any work or furnish any material not covered by this Contract, unless such work or materials is ordered in writing by the Borough. In no event shall the Borough be liable for any materials furnished or used, or for any work or labor done, unless the materials, work, or labor are required by the Contract or on written order furnished by the Borough. Any such work or materials which may be done or furnished by the Contractor without written order first being given shall be at the Contractor's own risk, cost, and expense and the Contractor hereby covenants and agrees to make no claim for compensation for work or materials done or furnished without such written order. 3. Payment under this Contract shall be outlined as one of the following options: Remote -Only Service for One Year, with Four (4) option years: not to exceed Seven Thousand One -Hundred Twenty -Five dollars ($7,125.00). This cost includes the annual licensing cost for the Niagara System Software. 4. The Contractor further covenants and agrees that all materials shall be furnished and delivered and all work and labor shall be done and performed, in every respect, to the satisfaction of the Borough, for the time frame allocated in the service agreement. [The Borough's signature below shall constitute notice to proceed.] It is expressly understood and agreed that in case of the failure on the part of the Contractor, for any reason, except with the written consent of the Borough, to complete the furnishing and delivery of materials and the doing and performance of the work before the aforesaid date, the Borough shall have the right to deduct from any Contract FY2026-43 Page 4 of 14 t Q4pa Page 2 of 2 0 money due or which may become due the Contractor, or if no money shall be due, the Borough shall have the right to recover Liquidated Damages as described in the Special Conditions for each calendar day elapsing between the time stipulated for achieving substantial completion of an individual phase and the actual date of completion of that phase in accordance with the terms hereof, such deduction to be made, or sum to be recovered, not as a penalty but as liquidated damages. Provided, however, that upon receipt of written notice from the Contractor of the existence of causes over which the Contractor has no control and which must delay furnishing of materials or the completion of the work, the Contracting Officer may, at his or her discretion, extend the period specified for the furnishing of materials or the completion of the work, and in such case the Contractor shall become liable for liquidated damages for delays commencing from the date on which the extended period expires. 5. The Contractor further covenants and agrees that the entire construction will be done under the administration of and to the complete satisfaction of the Borough subject to the inspection at all times and approval by any regulatory agency, and in accordance with the laws of the State of Alaska and the Borough. 6. For purposes of this Contract, Contracting Officer means the Borough Manager, or any other person designated by the Borough Manager. 7. The Contractor is an independent contractor and not an employee or agent of the Borough. 8. Contract Documents shall have the meaning ascribed by the General Conditions of the Construction Contract which can be found at Projects Office I Kodiak Island, AK - Official Website, and include but are not limited to this Contract, the General Conditions of the Construction Contract, the Special Conditions, and the following listed documents: (1) Borough Long Technologies Building Automation Support Service Agreement IN WITNESS WHEREOF the parties hereto have executed this Contract and agree to its terms and conditions. KODI K ISLAND``BOROUGH Signature of Borough Manager Printed Name Aimee Williams Dat 9W '�Or �� U144 Borough Clerk (Attest) NO- G CONTRACTOR LONG Building Technologies Company Name _glvltilp s�ynetl er erenaon mccarney Brendon McCarn eyDN: `-USE=bmccarney@londng1 G1g—,,CN-B T�chpobgies.OU=Alaska Builtling Intelligence. CN=Brentlon AMcGjrney n: y» Signature of Authorized Representative Brendon McCarney Printed Name of Authorized Representative 12/31/2025 Date Quote Number: PV7858 December 19, 2025 Contract FY2026-43 Page 5 of 14 L �,* N G" Page 3of12 Impact -Driven Service TM - LONG's Impact -Driven Service offering is shaping the future of Building Automation System service by turning the traditional reactive service model into a proactive service delivery environment that delivers more impact for your facility. As a part of the Impact -Driven Service offering, LONG utilizes the results of our advanced Fault Detection and Diagnostics (FDD) platform to analyze connected systems, identify faults, and prioritize findings to present the most valuable and impactful recommendations for your facility. This puts the power in your hands as the owner, manager, or operator of the facility to see the full picture and make the best decision on where and when to take action. Fault Detection and Diagnostics (FDD) — FDD is a state-of-the-art, bottom-up analytics tool that leverages data provided by your DDC BAS in order to quickly find and help the user prioritize faults, opportunities to improve occupant comfort or critical conditions, energy performance, and equipment longevity. Our FDD tool utilizes provided energy rate structures, selected equipment points, the capacity and type of systems, sequences of operation (SOO), and the hierarchical relationship of all your equipment and systems within its analytic algorithms. Detailed information on faults, opportunities, and root causes is provided and prioritized across building or equipment portfolios and by comfort, energy/cost, and maintenance in clear graphics and text. This prioritization, coupled with a built-in task management tool and customizable dashboard, allows users to increase their facilities management process efficiency, understand financial data on issues and upgrade/replacement opportunities, and to measure and verify results. LONG's Impact -Driven Service offering is made up of several keys components, and is customized to your specific facility's needs in order to provide the best possible value. Included in your service delivery are the following components: • FDD Onboarding (If Selected) • Live Analytics Platform • Analytics Reporting • Client Consultation (If Selected) • Service Technician Visits (If Selected) • Tridium Niagara System Maintenance (If Selected) • Field Device Maintenance (If Selected • Training and Support FDD Onboarding — All new sites and equipment covered under the Impact -Driven Service agreement will need to be onboarded to the FDD system. The onboarding process and supporting documentation are critical elements to the accuracy and overall success the service offering. LONG will manage the onboarding of your site(s) in the FDD platform using the following customer -provided information: • Utility Invoice Data o For deriving energy rate structures • Complete Points List (with full point path directory) o For establishing outbound data flow and understanding Sequences of Operation (SOO) • Complete Mechanical Drawings o For hierarchical relationships of all your equipment o For equipment capacities, flows, efficiencies, and ratings • Controls Drawings (TC) o For point infrastructure o For Sequences of Operation (SOO) Contract FY2026-43 Page 6 of 14 L N G Quote Number: PV7858 December 19, 2025 Page 4 of 12 • IT Support to Open Port 443 for secure Outbound -only access o For installation of the Data Transfer Service (DTS) to connect the BAS to the cloud LONG will work to customize the analytics toolset and ensure it's successful implementation. The typical timeline for the onboarding process is 90 days, which is critically dependent on receiving all of the customer provided information above as well as achieving system outbound access and successful DTS installation for Data Flow to proceed with setup, tuning, and quality assurance within 30 days of activation of the agreement. If any of the customer provided documentation listed above is unable to be provided to LONG in a timely fashion, or if remote connectivity is not established, the onboarding timeline will be extended, and the visit schedule as defined in the labor plan will begin to be executed as customer -directed visits until sufficient information can be gathered to complete the onboarding process. Live Analytics Platform — Clients may elect to have user access to the FDD Platform for as many users as desired. Setup will include at least one customer user administration account, allowing access to create, modify, and delete customer users. User access also includes basic client -specific targeted training based on your FDD results, which is typically offered 2-3 weeks after the building has been onboarded and turned over for operation. It is scheduled directly with the client and any of their desired users, and is typically a one-time, 1 hour session provided remotely. Alternatively, it may be offered in-person at the LONG Littleton office, or in some cases can arrange to be specifically scheduled at the customer site (local). Additional minor training, refresher training, or more in-depth training on specific items can also be addressed during scheduled client consultation meetings. Analytics Reporting — LONG will provide an annual analytics report that contains year -over -year data comparison, task completion status, and identified savings and/or optimization opportunities within your facility. This report will be delivered to the designated site contact(s) and can be reviewed together with LONG's team of experts during included consultation meetings. Quote Number: PV7858 Contract FY2026-43 Page 7 of 14 L 47" N G" December 19, 2025 Page 5 of 12 Client Consultation — Recommendations generated through the FDD system are reviewed on a regular basis to ensure that work being executed is in alignment with your highest priorities. Consultation Meetings: Recommendations are reviewed during regularly scheduled Client Consultation meetings where our team of experts meet with you to present the findings, discuss the impact to your facility, and determine action steps to be taken. LONG will review the FDD platform results with the customer at the agreed upon frequency in the labor plan. During these meetings, we will highlight the highest impact issues or faults, determine what tasks to prioritize, and discuss solutions to larger issues or faults requiring additional effort outside the visit schedule. The outcome of these discussions will help establish a Prioritized Plan that will serve as the roadmap for upcoming service visits and quoted solutions. Prioritized Plan: In preparation for remote visits, LONG will establish a Prioritized Plan for the highest impact priorities based on a suggested combination of the following: • Required device support needs • Important FDD faults and tasks • Other BAS or operational needs the client may otherwise deem highly important Client involvement in creating a Prioritized Plan is preferred and recommended, but not required. In the absence of Client participation, LONG will generate the Prioritized Plan and proceed with the scheduled visit, performing work that aligns with any previously documented priorities. Service Technician Visits — Remote technician visits are completed at regularly scheduled intervals to work through agreed-upon actions and tasks. Included visits will focus on resolving tasks that can be completed within the agreement visit schedule, troubleshooting of more complex issues to determine root cause, and the generation of recommended next steps to bring larger tasks to completion. Tasks can also be addressed under service calls, quoted repairs, or project proposals at the client's discretion. Remote Visits: LONG will be scheduled to remotely access the site at a minimum frequency designated in the agreement. Scheduled remote visits include the time required for reviewing the FDD platform findings, necessary device maintenance (if selected), and prioritized tasking as identified through the Client Consultation process. In some cases, if the issue warrants a physical site visit, LONG may elect to include one at its discretion. They may work with site personnel or additional vendors to accomplish tasks if possible. If a certain task cannot be completed remotely, it will be delayed until the next scheduled on-site visit. Examples of tasks that can typically be completed within include Impact -Driven Service visits: Adjusting/Optimizing existing DDC system settings, such as: o Schedules o Setpoints o Time delays o Triggers o Thresholds Tuning PID control loops Assistance with identifying minor mechanical problems Quote Number: PV7858 Contract FY2026-43 Page 8 of 14 December 19, 2025 Page 6 of 12 N Go Examples of tasks that require additional effort beyond the Impact -Driven Service visits are: • Replacement of physical components, including sensors, actuators, controllers, and more • Calibration or repair of existing sensors • In-depth or advanced troubleshooting • Extensive labor solutions such as (but not limited to) the following items: o Sequence of operation and programming changes o Major revisions or an overhaul to address pre-existing shortcomings due to poorly installed or designed systems Individual task completion cannot be guaranteed during visits, as tasks can vary widely in complexity, LONG will provide updated information after each visit to indicate what tasks were able to be resolved, along with recommended next steps for any high-priority tasks that are still open. Excluded items may arise that exceed the customary tasks and scope of this agreement. Furthermore, additional faults or needs could arise outside of planned visit frequency and standard of care. In either instance, LONG is available to assist you in scheduling additional preferred -rate service calls and/or quoted repairs outside the scope of this agreement. LONG will coordinate with the designated site contact(s) to schedule client consultation meetings, onsite visits, and remote visits (as required). The correspondence may include phone calls, email, and calendar invitations. A planned visit obligation may be deemed fulfilled if any of the following occurs: • LONG completes the scheduled visit according to the Impact -Driven Service labor plan. • LONG and the customer mutually agree to skip a scheduled visit. • The visit is unable to be successfully scheduled after multiple attempts to coordinate have been made by LONG's Service Dispatch team. If this is the case, a final notification will be sent to all parties to confirm that the visit is being skipped. LONG must be informed of any designated site contact changes and recommends that the client provide backup contact information to avoid relinquishing collaboration and/or scheduled visits. Tridium Niagara System Maintenance — LONG is providing maintenance for the Niagara devices within your system. We will maintain licensing, install patches, and keep your system up to date within the supported software versions available from Tridium. This also depends on the safety or criticality of the update and is dependent on scheduling during each service year. The technicians will also keep a database of Niagara backups within the cloud. They perform regularly scheduled installations of LONG -approved Windows updates and maintenance for your firewall settings, as well as any other system -related software on your front-end PC, as prioritized during scheduled onsite visits throughout the annual service term. LONG monitors memory usage, hard drive space, and platform and station performance of each device. They support and maintain your user accounts and passwords by request. Field Device Maintenance — LONG is providing support for the subordinate devices within your system. This includes monitoring and adjusting your communication settings as necessary to optimize speed and bus traffic. LONG will perform system patches and firmware updates within the supported versions available, and perform regular backups which will be stored within the cloud. If device maintenance is excluded: Support for the subordinate devices within the system including monitoring and adjusting your communication settings as necessary to optimize speed and bus traffic, perform system patches and firmware updates within the supported versions available, and perform regular backups which will be stored within the cloud can be added to this service agreement. Contract FY2026-43 Page 9 of 14 N G" Quote Number: PV7858 December 19, 2025 Page 7 of 12 Training and Support — LONG provides the following additional training and support offerings to our service agreement customers at no additional cost. Buildinq Automation System Training: LONG provides analytics clients with access to the customer training classes at LONG, included on the seasonal schedule. The classes offered include Niagara system (BAS) training, basic FDD system user training as well as more advanced classes on the portal/dashboards and the diagnostics and task management tools in a combined customer setting. Remote Support: If remote BAS access is available to your site, courtesy remote support calls are included in the service, and are available for 30 minutes or less during normal business hours. • This agreement includes the equivalent number of annual courtesy remote support calls as the total number of annual planned visits (Onsite and Remote Planned). • Courtesy remote support calls are to be used to identify a problem, advise customer on repairs, and answer customer questions. LONG will advise if a billable service call is required for the identified repairs. Summarized Visit & Meeting Frequency Plan Proposed Labor Schedule Borough Building - AK Year Term - Impact -Driven Service TM Jan Feb Mar Apr May Jun Jul Aug Sep Oct Nov Dec Annual Frequency Device Maintenance (SMAS) 1 Onsite Visit 0 Remote Visit 2 Client Consultation 2 Onboarding (Yr 1) — *The summarized visit and meeting frequency represented above indicates the generally intended agreement service schedule, but the actual dates may vary or be adjusted for weather, scheduling needs, FDD results, access, etc During the onboarding period, LONG will fulfill any included Onsite and/or Remote visits as customer -directed visits. During these visits, LONG will fulfill contractual device support/maintenance updates, and will be available to address any other customer -directed issues/concerns during the scheduled visit time. Upon completion of onboarding, LONG will evaluate the labor plan and may elect to schedule an additional Client Consultation meeting if one is not coming up soon in order to review the FDD platform with the client, establish priorities, and initiate future visits based on the prioritized plan. Contract FY2026-43 Page 10 of 14 L iovk, N Gw Quote Number: PV7858 December 19, 2025 Page 8 of 12 Service Summary and Equipment List Annual maintenance includes Device and FDD support for the following equipment and selections: Fault Detection and Diagnostics (FDD) Qty Onboarding and Support 1 Onboarding Kickoff 1 Onboarding and Installation Support 1 Impact -Driven Service Turnover 1 Unlimited User Access 1 User Training 1 Ongoing Impact -Driven Services Traditional Device Support Qty Device Maintenance 1 PC/Server and Cloud Support 1 JACE Support 0 Field Device (VO Controller) Support 0 Add Customer -Directed Support (Hours) Fault Detection and Diagnostics (FDD) Scope FDD Equipment (Qty) on Platform Bldg Total QtY Device Support Scope Chiller 0 0 Stations Covered Qty Cooling Tower 0 0 Boiler 2 2 Pumps 3 3 S-1\14-0 0 Heat Exchanger 1 1 S-1\14-1 0 Storage Tank 0 0 S-1\14-2 1 Air Handler 1 1 S-1\14-3 0 Stand Alone Fan 0 0 S -N4-10 0 Zone equipment 8 8 S -N-100 0 Utility Meters 0 0 S-N-UNL 0 Other Simple Equipment 1 1 Other Complex Equipment 0 0 Building 1 1 JACE-8005 1 Quote Number: PV7858 Contract FY2026-43 Page 11 of 14 L N G "' December 19, 2025 Page 9 of 12 Term, Billing, and Payment This Agreement will go into effect on the 1 st day of the month following the date of the Customer's signature and will continue for 5 years through the last day of the 60th month, unless either party gives written notice to the other of the intention not to renew the Agreement, upon which any price adjustment will be made at that time with a guaranteed increase cap of 5% of the prior year's investment. This agreement will automatically renew on an annual basis until a new Agreement is executed. Either party may terminate this Agreement upon 30 days' written notice. In the event this Agreement is terminated by LONG or the Customer, all costs are due for actual work accomplished in accordance with this Agreement, during the duration, and up to that point, prior to the final termination of the Agreement. LONG will invoice for services rendered in accordance with this Agreement, to that date, including the labor, material cost, and fees associated with the analytics platform. Alaska Controls Service Rates and Response As an Agreement Customer, you will enjoy priority response ahead of non -contract customers, our best rates, and access to LONG's On -Call and After -Hours emergency service 24 hours a day, 7 days a week, 365 days a year. The following rates and associated terms in this section below refer to work done outside of the scope of the Agreement. • Alaska Controls Service Rates for the current contract year o Hourly Controls Technician Service Rate: $238.00/Hr. o Hourly Controls Technician Service Rate for Contract Customers: $202.00/Hr. • Overtime Hourly Rates: 1'/2 times Regular Rate outside LONG's Business Hours (Monday through Friday 7:00 a.m. to 4:00 p.m.). 2 times Regular Rate on National Holidays. • The minimum time to be charged for service work is 2 hours. If the service work can be done remotely and a site visit is not necessary, a minimum charge of 1 hour will be applied. Thereafter, time will be charged in'/2 hour increments. Any after-hours emergency service calls shall be charged the minimums and '/2 hour increments thereafter at the overtime and double time rates. • Each additional unplanned overnight stay will incur a flat fee of $1,800 per night per person. The service rates shown above are for the current calendar year and are subject to change each year, effective January 1St to adjust for market changes. 3rd Party Access Requirements LONG partners with Clockworks Analytics (KGS Buildings Inc) to provide the FDD software platform used as a part of the Impact -Driven Service agreement. Clockworks Analytics must be granted remote access to the building automation system through the same access method that LONG uses in order to facilitate the setup and ongoing maintenance of the FDD data connection. Clockwork Analytics will configure remote outbound access between the Customer's building automation system (BAS) and Clockwork Analytics' secure Azure - based cloud service to enable the Software as a Service (SaaS) for the FDD platform. Clockworks is separately insured for Network Security & Privacy Liability. LONG and LONG personnel are not liable for site network security breaches on the building automation network or any other local network that result from actions taken by Clockworks Analytics. Contract FY2026-43 Page 12 of 14 L N G "' Quote Number: PV7858 December 19, 2025 Page 10 of 12 Yearly investment for this 1 Year Remote -Only Agreement with 4 optional Years: Billed Quarterly at One Thousand Seven Hundred Eighty -One Dollars Twenty -Five Cents .........$1,781.25 Annual equivalent is $7,125 (Includes Onboarding Costs*) Includes: 2 Remote Visits and 2 Analytic Reviews per year The following agreement includes upfront costs incurred by LONG to be spread out evenly throughout the anticipated term of this agreement, billed quarterly at $630.80 for 60 months. If either party determines the necessity to terminate the agreement prior to the full-term expiration; LONG will invoice for any and all remaining costs incurred on the final invoice. Your Building Technology Partner, Account Executive LONG Building Technologies, Inc 907-315 -4844 Accepted by, V Vel av� Authorized Signature Aimee Williams, Manager 4 S'TACN Zb Printed Name Date: PO# On Behalf Of: Kodiak Island Borough 710 Mill Bay Rd Kodiak, AK 99615 n gSSF�,�,.�c f w� oatt qwo l 151?n� Nova M. Javier Date Borough Clerk, Attest ®eJ�Q►i� � �� Q _ ZA �k �9�,�.SKA�� Contract FY2026-43 Page 13 of 14 Li�"N Gw Quote Number: PV7858 December 19, 2025 Page 11 of 12 Building Automation Service Agreement - Terms and Conditions of Sale Contract Formation: • LONG Building Technologies, Inc. ("LONG") agrees to provide services, materials, and equipment in accordance with these Terms and Conditions. • Acceptance occurs when the Customer issues a purchase order, signs a contract, submits written approval, or permits LONG to begin work. • Any conflicting or additional terms proposed by Customer are rejected unless explicitly approved in writing by LONG. • These Terms constitute the full and final agreement between LONG and Customer and supersede prior or concurrent understandings, written or verbal. 2. Financial Terms a. Billing and Credit • Prior to ordering materials or scheduling work, Customer must submit sufficient credit information to establish billing terms. • LONG assigns a credit limit and payment terms based on Customer's credit profile. Standard terms: Net 30 days from invoice. • LONG may invoice in full or in progress as materials or services are delivered. b. Fees and Collections • Credit card payments incur applicable processing fees. • Unpaid balances accrue interest at 1.5% per month. • LONG may suspend service until delinquent accounts are paid. • Customer is liable for all collection and enforcement costs, including attorney's fees. C. Change in Ownership or Responsible Party • The Customer listed at service commencement remains financially liable for all charges, regardless of property ownership changes or payee reassignment, unless LONG provides written release. d. Taxes • Prices exclude sales, use, and excise taxes unless stated. Customer is responsible for all applicable taxes. Risk Allocation a. Warranty • LONG warrants its workmanship and materials for 90 days from service date and passes on the original manufacturer's warranty (typically one year from LONG's purchase). • Warranty excludes misuse, Acts of God, third -party intervention, subcontracted services, and after-hours warranty labor. b. Limitation of Liability • LONG is not liable for incidental, consequential, or special damages, including those arising from suspension of services due to unresolved safety risks or delinquent balances. • Maximum liability is limited to the amount paid under the applicable contract. • All claims must be made within the warranty period. c. Indemnification • Customer agrees to indemnify, defend, and hold harmless LONG and its personnel against any claims, damages, or losses arising from Customer's breach, negligence, or misuse of LONG's work, services, or equipment. Service Scope and Conditions a. Standard Service Window and Access • Service hours are 7:00 AM -4:00 PM, Monday through Friday, excluding holidays. • After-hours service incurs additional charges. • Customer must ensure timely and safe access to equipment and work areas. b. Service Exclusions - LONG does not provide or assume responsibility for: • Work involving hazardous materials (animal waste, asbestos, mold, lead, etc.) unless explicitly contracted • Hazardous material testing, containment, or abatement • Relocation of equipment or physical modifications to access areas • Troubleshooting outside the quoted scope of work • Network security or cyber risks, including viruses, malware, unauthorized access, or data loss. LONG does not monitor, protect, or configure network systems unless specifically contracted. Customer assumes all risks of integrating LONG's work within network environments. c. Site Conditions • Customer warrants that the service site meets all applicable safety and regulatory standards. • LONG may halt work if site conditions are deemed unsafe or non-compliant. Delays or associated costs are the Customer's responsibility. Contract FY2026-43 Page 14 of 14 L N Gw Quote Number: PV7858 December 19, 2025 Page 12 of 12 5. Termination and Assignment • Either party may terminate with 30 days written notice. • Customer must pay for all completed work, including labor, materials, and related costs. • This agreement may not be assigned without written consent from LONG. 6. Employment Protections • Neither party shall recruit or hire the other's employees during the contract and for one year thereafter. • Violations are subject to damages equal to three years' wages and benefits of the solicited employee. Legal Terms a. Dispute Resolution • All disputes will be resolved via binding arbitration under the Commercial Arbitration Rules of the American Arbitration Association. • Venue: Littleton, Colorado, unless mutually agreed otherwise. • Discovery will follow Federal Rules of Civil Procedure and conclude within four months of filing. b. Force Majeure • LONG is not liable for delays or failures due to events beyond its control, including natural disasters, pandemics, labor disputes, government actions, or supply disruptions. c. Intellectual Property • Designs, documentation, software, and proprietary materials created or supplied by LONG remain LONG's exclusive property. • Customer may not replicate, disclose, or use LONG's intellectual property without written permission. d. Electronic Communications • Customer agrees that electronic communications and digital signatures are binding and enforceable under this agreement. Vol. FY2026, No. 12 Kodiak Island Borough Assembly Newsletter December 19, 2025 At Its Regular Meeting Of December 18, 2025, The Kodiak Island Borough Assembly Took The Following Actions. The Next Regular Meeting Of The Borough Assembly Is Scheduled On Thursday, January 15, 2026, At 6:30 p.m. In The Borough Assembly Chambers. ADOPTED Ordinance No. FY2026-13, Accepting And Appropriating Funds From The 2020 Alaska Pacific Cod Federal Fishery Disaster Relief Distribution ADOPTED Ordinance No. FY2026-14, Accepting And Appropriating Funds From The 2021 Chignik Salmon Federal Fishery Disaster Relief Distribution POSTPONED The Contract No. FY2026-25 For The Landfill Scale Shack Platform Replacement With CCI Industrial Services, LLC To The Next Regular Meeting Of The Assembly On January 15, 2026 AUTHORIZED The Borough Manager To Execute Contract No. FY2026-42, Port Lions School Emergency Fire Alarm Panel Replacement With Taylor Fire Protection In The Amount Of $169,292 AUTHORIZED The Borough Manager To Execute Contract No. FY2026-43, Borough Building Automation Services Agreement With Long Building Technologies AUTHORIZED The Borough Manager To Execute Contract No. FY2026-44, Kodiak Fisheries Research Center Long Building Technologies Building Automation Service Agreement ADVANCED Ordinance No. FY2026-16, Amending Kodiak Island Borough Code Chapter 5.01 Regarding Liquor Licenses To Clarify The Methods And Basis For Borough Protests For Issuance Of A New License, Renewal Of An Existing License, Transfer Of An Existing License, And Review Of The Continued Operation Of A License To Public Hearing At The Next Regular Meeting Of The Assembly CONFIRMED The Mayoral Appointments Of The Following: • Brian Himelbloom And Joseph Mauer For Terms To Expire December 31, 2028 On The Parks And Recreation Committee • Sara Fraser For A Term To Expire December 31, 2028 On The Planning And Zoning Commission Borough Seat • Alicia Flores, Judith Phillips, And Lawrence Van Daele To The At Large Seats For Terms To Expire December 31, 2028 On The Solid Waste Advisory Board And Assembly Appointments Of Randal Ensign And David Zimmerman For Terms To Expire December 31, 2028 On The Mission Lake Tidegate Service Area CONFIRMED The Assembly Appointment Of Mr. Blake Strain To The Womens Bay Service Area Board For A Term To Expire October 2028 View our website: T7 Visit our Facebook page: www.kodiakak.us www.facebook.com/KodiakislandBorough ACCEPTED, With Regret, The Resignation Of Mr. Nick Mangini From The Planning And Zoning Commission, City Seat, Effective December 17, 2025, DECLARED The Seat Vacant, And DIRECTED The Borough Clerk To Advertise The Vacancy In Accordance With Borough Code 2.100.070(D) ACCEPTED With Regret, The Resignation Of Mr. Victor Weaver From The Architectural And Engineering Review Board, Effective December 5, 2025, DECLARED The Seat Vacant, And DIRECTED The Borough Clerk To Advertise The Vacancy In Accordance With Borough Code 2.100.070(D) View our website: Visit our Facebook page: www.kodiakak.us www.facebook.com/KodiakislandBorough